GENERAL SERVICES ADMINISTRATION ACQUISITION MANUAL (GSAM)

#### 552.232-1 Payments. As prescribed in 532.7104, insert the following clause: Payments (Apr 1984) (Deviation FAR 52.232-1) (a) The Government shall pay the Contractor, without submission of invoices or vouchers, 30 days after the service period, the prices stipulated in this contract for supplies delivered and accepted or services rendered and accepted, less any deductions provided in this contract. (b) Unless otherwise specified in this contract, the Government will make payment on partial deliveries accepted by the Government if either: (1) The amount due on the deliveries warrants it. (2) The Contractor requests it and the amount due on the deliveries is at least $1,000 or 50 percent of the total contract price. (c) When processing payment, GSA’s Finance Office will automatically generate the 12 digit invoice number using the ACT number assigned to the contract, followed by an abbreviated month and year of service (e.g., 84261554JUN7, for June 1997). The ACT number appears on the contract award document. (End of clause) #### 552.232-8 Discounts for Prompt Payment. As prescribed in 532.206, insert the following clause: Discounts for Prompt Payment (Apr 1989) (Deviation FAR 52.232-8) (a) Discounts for early payment (hereinafter referred to as “discounts” or “the discount”) will be considered in evaluating the relationship of the offeror’s concessions to the Government vis-a-vis the offeror’s concessions to its commercial customers, but only to the extent indicated in this clause. (b) Discounts will not be considered to determine the low offeror in the situation described in the “Offers on Identical Products” provision of this solicitation. (c) Uneconomical discounts will not be considered as meeting the criteria for award established by the Government. In this connection, a discount will be considered uneconomical if the annualized rate of return for earning the discount is lower than the “value of funds” rate established by the Department of the Treasury and published quarterly in the Federal Register. The “value of funds” rate applied will be the rate in effect on the date specified for the receipt of offers. (d) Agencies required to use the resultant schedule will not apply the discount in determining the lowest delivered price pursuant to the FPMR, 41 CFR 101-26.408, if the agency determines that payment will probably not be made within the discount period offered. The same is true if the discount is considered uneconomical at the time of placement of the order. (e) Discounts for early payment may be offered either in the original offer or on individual invoices submitted under the resulting contract. Discounts offered will be taken by the Government if payment is made within the discount period specified. (f) Discounts that are included in offers become a part of the resulting contracts and are binding on the Contractor for all orders placed under the contract. Discounts offered only on individual invoices will be binding on the Contractor only for the particular invoice on which the discount is offered. (g) In connection with any discount offered for prompt payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the date on which an electronic funds transfer was made. (End of clause) Alternate I (May 2003). As prescribed in 532.206(a), remove paragraph (d) and redesignate paragraphs (e), (f), and (g) as (d), (e), and (f), respectively. #### 552.232-23 Assignment of Claims. As prescribed in 532.806, insert the following clause: Assignment of Claims (Sep 1999) Because this is a requirements or indefinite quantity contract under which more than one agency may place orders, paragraph (a) of the Assignment of Claims clause (FAR 52.232-23) is inapplicable and the following is substituted therefor: In order to prevent confusion and delay in making payment, the Contractor shall not assign any claim(s) for amounts due or to become due under this contract. However, the Contractor is permitted to assign separately to a bank, trust company, or other financial institution, including any Federal lending agency, under the provisions of the Assignment of Claims Act, as amended, 31 U.S.C. 3727, 41 U.S.C. 15 (hereinafter referred to as “the Act”), all amounts due or to become due under any order amounting to $1,000 or more issued by any Government agency under this contract. Any such assignment takes effect only if and when the assignee files written notice of the assignment together with a true copy of the instrument of assignment with the contracting officer issuing the order and the finance office designated in the order to make payment. Unless otherwise stated in the order, payments to an assignee of any amounts due or to become due under any order assigned may, to the extent specified in the Act, be subject to reduction or set-off. (End of clause) #### 552.232-25 Prompt Payment. As prescribed in 532.908(a)(2), insert the following clause: Prompt Payment (Jul 1998) (Deviation FAR 52.232-25) Notwithstanding any other payment clause in this contract, the Government will make invoice payments and contract financing payments under the terms and conditions specified in this clause. Payment shall be considered as being made on the day a check is dated or the date of an electronic funds transfer. Definitions of pertinent terms are set forth in section 32.902 of the Federal Acquisition Regulation. All days referred to in this clause are calendar days, unless otherwise specified. (However, see paragraph (g)(4) of this clause concerning payments due on Saturdays, Sundays, and legal holidays.) (a) Invoice payments. (1) The due date for making invoice payments by the designated payment office is: (i) For orders placed electronically by the General Services Administration (GSA) Federal Supply Service (FSS), and to be paid by GSA through electronic funds transfer (EFT), the later of the following two events: (A) The 10th day after the designated billing office receives a proper invoice from the Contractor. If the designated billing office fails to annotate the invoice with the date of receipt at the time of receipt, the invoice payment due date shall be the 10th day after the date of the Contractor's invoice; provided the Contractor submitted a proper invoice and no disagreement exists over quantity, quality, or Contractor compliance with contract requirements. (B) The 10th day after Government acceptance of supplies delivered or services performed by the Contractor. (ii) For all other orders, the later of the following two events: (A) The 30th day after the designated billing office receives a proper invoice from the Contractor. If the designated billing office fails to annotate the invoice with the date of receipt at the time of receipt, the invoice payment due date shall be the 30th day after the date of the Contractor's invoice; provided the Contractor submitted a proper invoice and no disagreement exists over quantity, quality, or Contractor compliance with contract requirements. (B) The 30th day after Government acceptance of supplies delivered or services performed by the Contractor. (iii) On a final invoice, if the payment amount is subject to contract settlement actions, acceptance occurs on the effective date of the contract settlement. (2) The General Services Administration will issue payment on the due date in paragraph (a)(1)(i) of this clause if the Contractor complies with full cycle electronic commerce. Full cycle electronic commerce includes all the following elements: (i) The Contractor must receive and fulfill electronic data interchange (EDI) purchase orders (transaction set 850). (ii) The Contractor must generate and submit to the Government valid EDI invoices (transaction set 810) or submit invoices through the GSA Finance Center Internet-based invoice process. Internet-based invoices must be submitted using procedures provided by GSA. (iii) The Contractor’s financial institution must receive and process, on behalf of the Contractor, EFT payments through the Automated Clearing House (ACH) system. (iv) The EDI transaction sets in paragraphs (a)(2)(i) through (a)(2)(iii) of this clause must adhere to implementation conventions provided by GSA. (3) If any of the conditions in paragraph (a)(2) of this clause do not occur, the 10 day payment due dates in (a)(1) become 30 day payment due dates. (4) Certain food products and other payments. (i) Due dates on Contractor invoices for meat, meat food products, or fish; perishable agricultural commodities; and dairy products, edible fats or oils, and food products prepared from edible fats or oils are— (A) For meat or meat food products, as defined in section 2(a)(3) of the Packers and Stockyard Act of 1921 (7 U.S.C. 182(3)), and as further defined in Pub. L. 98-181, including any edible fresh or frozen poultry meat, any perishable poultry meat food product, fresh eggs, and any perishable egg product, as close as possible to, but not later than, the 7th day after product delivery. (B) For fresh or frozen fish, as defined in section 204(3) of the Fish and Seafood Promotion Act of 1986 (16 U.S.C. 4003(3)), as close as possible to, but not later than, the 7th day after product delivery. (C) For perishable agricultural commodities, as defined in section 1(4) of the Perishable Agricultural Commodities Act of 1930 (7 U.S.C. 499a(4)), as close as possible to, but not later than, the 10th day after product delivery, unless another date is specified in the contract. (D) For dairy products, as defined in section 111(e) of the Dairy Production Stabilization Act of 1983 (7 U.S.C. 4502(e)), edible fats or oils, and food products prepared from edible fats or oils, as close as possible to, but not later than, the 10th day after the date on which a proper invoice has been received. Liquid milk, cheese, certain processed cheese products, butter, yogurt, ice cream, mayonnaise, salad dressings, and other similar products, fall within this classification. Nothing in the Act limits this classification to refrigerated products. When questions arise regarding the proper classification of a specific product, prevailing industry practices will be followed in specifying a contract payment due date. The burden of proof that a classification of a specific product is, in fact, prevailing industry practice is upon the Contractor making the representation. (ii) If the contract does not require submission of an invoice for payment (e.g., periodic lease payments), the due date will be as specified in the contract. (5) Contractor’s invoice. The Contractor shall prepare and submit invoices to the designated billing office specified in the contract. Notwithstanding paragraph (g) of the clause at FAR 52.212-4, Contract Terms and Conditions—Commercial Items, if the Contractor submits hard-copy invoices, submit only an original invoice. No copies of the invoice are required. A proper invoice must include the items listed in paragraphs (a)(5)(i) through (a)(5)(viii) of this clause. If the invoice does not comply with these requirements, it shall be returned within 7 days after the date the designated billing office received the invoice (3 days for meat, meat food products, or fish; 5 days for perishable agricultural commodities, edible fats or oils, and food products prepared from edible fats or oils), with a statement of the reasons why it is not a proper invoice. Untimely notification will be taken into account in computing any interest penalty owed the Contractor in the manner described in paragraph (a)(5) of this clause. (i) Name and address of the Contractor. (ii) Invoice date. (The Contractor is encouraged to date invoices as close as possible to the date of the mailing or transmission.) (iii) Contract number or other authorization for supplies delivered or services performed (including order number and contract line item number). (iv) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed. (v) Shipping and payment terms (e.g., shipment number and date of shipment, prompt payment discount terms). Bill of lading number and weight of shipment will be shown for shipments on Government bills of lading. (vi) Name and address of Contractor official to whom payment is to be sent (must be the same as that in the contract or in a proper notice of assignment). (vii) Name (where practicable), title, phone number, and mailing address of person to be notified in the event of a defective invoice. (viii) Any other information or documentation required by the contract (such as evidence of shipment). (ix) While not required, the Contractor is strongly encouraged to assign an identification number to each invoice. (6) Interest penalty. An interest penalty shall be paid automatically by the designated payment office, without request from the Contractor, if payment is not made by the due date and the conditions listed in paragraphs (a)(6)(i) through (a)(6)(iii) of this clause are met, if applicable. However, when the due date falls on a Saturday, Sunday, or legal holiday when Federal Government offices are closed and Government business is not expected to be conducted, payment may be made on the following business day without incurring a late payment interest penalty. (i) A proper invoice was received by the designated billing office. (ii) A receiving report or other Government documentation authorizing payment was processed, and there was no disagreement over quantity, quality, or Contractor compliance with any contract term or condition. (iii) In the case of a final invoice for any balance of funds due the Contractor for supplies delivered or services performed, the amount was not subject to further contract settlement actions between the Government and the Contractor. (7) Computing penalty amount. The interest penalty shall be at the rate established by the Secretary of the Treasury under section 12 of the Contract Disputes Act of 1978 (41 U.S.C. 611) that is in effect on the day after the due date, except where the interest penalty is prescribed by other governmental authority (e.g., tariffs). This rate is referred to as the “Renegotiation Board Interest Rate,” and it is published in the Federal Register semiannually on or about January 1 and July 1. The interest penalty shall accrue daily on the invoice principal payment amount approved by the Government until the payment date of such approved principal amount; and will be compounded in 30-day increments inclusive from the first day after the due date through the payment date. That is, interest accrued at the end of any 30-day period will be added to the approved invoice principal payment amount and will be subject to interest penalties if not paid in the succeeding 30-day period. If the designated billing office failed to notify the Contractor of a defective invoice within the periods prescribed in paragraph (g)(5) of this clause, the due date on the corrected invoice will be adjusted by subtracting from such date the number of days taken beyond the prescribed notification of defects period. Any interest penalty owed the Contractor will be based on this adjusted due date. Adjustments will be made by the designated payment office for errors in calculating interest penalties. (i) For the sole purpose of computing an interest penalty that might be due the Contractor, Government acceptance shall be deemed to have occurred constructively on the 7th day (unless otherwise specified in this contract) after the Contractor delivered the supplies or performed the services in accordance with the terms and conditions of the contract, unless there is a disagreement over quantity, quality, or Contractor compliance with a contract provision. In the event that actual acceptance occurs within the constructive acceptance period, the determination of an interest penalty shall be based on the actual date of acceptance. The constructive acceptance requirement does not, however, compel Government officials to accept supplies or services, perform contract administration functions, or make payment prior to fulfilling their responsibilities. (ii) The following periods of time will not be included in the determination of an interest penalty: (A) The period taken to notify the Contractor of defects in invoices submitted to the Government, but this may not exceed 7 days (3 days for meat, meat food products, or fish; 5 days for perishable agricultural commodities, dairy products, edible fats or oils, and food products prepared from edible fats or oils). (B) The period between the defects notice and resubmission of the corrected invoice by the Contractor. (C) For incorrect electronic funds transfer (EFT) information, in accordance with the EFT clause of this contract. (iii) Interest penalties will not continue to accrue after the filing of a claim for such penalties under the clause at 52.233-1, Disputes, or for more than 1 year. Interest penalties of less than $1 need not be paid. (iv) Interest penalties are not required on payment delays due to disagreement between the Government and the Contractor over the payment amount or other issues involving contract compliance or on amounts temporarily withheld or retained in accordance with the terms of the contract. Claims involving disputes, and any interest that may be payable, will be resolved in accordance with the clause at 52.233-1, Disputes. (8) Prompt payment discounts. An interest penalty also shall be paid automatically by the designated payment office, without request from the Contractor, if a discount for prompt payment is taken improperly. The interest penalty will be calculated as described in paragraph (g)(7) of this clause on the amount of discount taken for the period beginning with the first day after the end of the discount period through the date when the Contractor is paid. (9) Additional interest penalty. (i) If this contract was awarded on or after October 1, 1989, a penalty amount, calculated in accordance with paragraph (a)(9)(iii) of this clause, shall be paid in addition to the interest penalty amount if the Contractor— (A) Is owed an interest penalty of $1 or more; (B) Is not paid the interest penalty within 10 days after the date the invoice amount is paid; and (C) Makes a written demand to the designated payment office for additional penalty payment, in accordance with paragraph (a)(9)(ii) of this clause, postmarked not later than 40 days after the invoice amount is paid. (ii) (A) Contractors shall support written demands for additional penalty payments with the following data. No additional data shall be required. Contractors shall— (1) Specifically assert that late payment interest is due under a specific invoice, and request payment of all overdue late payment interest penalty and such additional penalty as may be required; (2) Attach a copy of the invoice on which the unpaid late payment interest was due; and (3) State that payment of the principal has been received, including the date of receipt. (B) Demands must be postmarked on or before the 40th day after payment was made, except that— (1) If the postmark is illegible or nonexistent, the demand must have been received and annotated with the date of receipt by the designated payment office on or before the 40th day after payment was made; or (2) If the postmark is illegible or nonexistent and the designated payment office fails to make the required annotation, the demand's validity will be determined by the date the Contractor has placed on the demand; provided such date is no later than the 40th day after payment was made. (iii) (A) The additional penalty shall be equal to 100 percent of any original late payment interest penalty, except— (1) The additional penalty shall not exceed $5,000; (2) The additional penalty shall never be less than $25; and (3) No additional penalty is owed if the amount of the underlying interest penalty is less than $1. (B) If the interest penalty ceases to accrue in accordance with the limits stated in paragraph (a)(5)(iii) of this clause, the amount of the additional penalty shall be calculated on the amount of interest penalty that would have accrued in the absence of these limits, subject to the overall limits on the additional penalty specified in subdivision (a)(7)(iii)(A) of this clause. (C) For determining the maximum and minimum additional penalties, the test shall be the interest penalty due on each separate payment made for each separate contract. The maximum and minimum additional penalty shall not be based upon individual invoices unless the invoices are paid separately. Where payments are consolidated for disbursing purposes, the maximum and minimum additional penalty determination shall be made separately for each contract therein. (D) The additional penalty does not apply to payments regulated by other Government regulations (e.g., payments under utility contracts subject to tariffs and regulation). (b) Contract financing payments. (1) Due dates for recurring financing payments. If this contract provides for contract financing, requests for payment shall be submitted to the designated billing office as specified in this contract or as directed by the Contracting Officer. Contract financing payments shall be made on the [insert day as prescribed by Agency head; if not prescribed, insert 30th day] day after receipt of a proper contract financing request by the designated billing office. In the event that an audit or other review of a specific financing request is required to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the due date specified. (2) Due dates for other contract financing. For advance payments, loans, or other arrangements that do not involve recurring submissions of contract financing requests, payment shall be made in accordance with the corresponding contract terms or as directed by the Contracting Officer. (3) Interest penalty not applicable. Contract financing payments shall not be assessed an interest penalty for payment delays. (c) Fast payment procedure due dates. If this contract contains the clause at 52.213-1, Fast Payment Procedure, payments will be made within 15 days after the date of receipt of the invoice. (End of clause) #### 552.232-70 Invoice Requirements. As prescribed in 532.111(a), insert the following clause: Invoice Requirements (Sep 1999) (a) Invoices shall be submitted in an original only, unless otherwise specified, to the designated billing office specified in this contract or order. (b) Invoices must include the Accounting Control Transaction (ACT) number provided below or on the order. ACT Number [Contracting Officer insert number] (c) In addition to the requirements for a proper invoice specified in the Prompt Payment clause of this contract or order, the following information or documentation must be submitted with each invoice: [Contracting Officer list additional requirements.] (End of clause) #### 552.232-71 Adjusting Payments. As prescribed in 532.111(b), insert the following clause: Adjusting Payments (Sep 1999) (a) Under the Inspection of Services clause of this contract, payments may be adjusted if any services do not conform with contract requirements. The Contracting Officer or a designated representative will inform the Contractor, in writing, of the type and dollar amount of proposed deductions by the 10th workday of the month following the performance period for which the deductions are to be made. (b) The Contractor may, within 10 working days of receipt of the notification of the proposed deductions, present to the Contracting Officer specific reasons why any or all of the proposed deductions are not justified. Reasons must be solidly based and must provide specific facts that justify reconsideration and/or adjustment of the amount to be deducted. Failure to respond within the 10-day period will be interpreted to mean that the Contractor accepts the deductions proposed. (c) All or a portion of the final payment may be delayed or withheld until the Contracting Officer makes a final decision on the proposed deduction. If the Contracting Officer determines that any or all of the proposed deductions are warranted, the Contracting Officer shall so notify the Contractor, and adjust payments under the contract accordingly. (End of clause) #### 552.232-72 Final Payment. As prescribed in 532.111(c), insert the following clause: Final Payment (Sep 1999) Before final payment is made, the Contractor shall furnish the Contracting Officer with a release of all claims against the Government relating to this contract, other than claims in stated amounts that are specifically excepted by the Contractor from the release. If the Contractor’s claim to amounts payable under the contract has been assigned under the Assignment of Claims Act of 1940, as amended (31 U.S.C. 3727, 41 U.S.C. 15), a release may also be required of the assignee. (End of clause) #### 552.232-73 Availability of Funds. As prescribed in 532.705-1, insert the following clause: Availability of Funds (Sep 1999) The authorization of performance of work under this contract during the initial contract period and any option or extension period(s) is contingent upon the appropriation of funds to procure this service. If the contract is awarded, extended, or option(s) exercised, the Government’s obligation beyond the end of the fiscal year (September 30), in which the award or extension is made or option(s) exercised, is contingent upon the availability of funds from which payment for the contract services can be made. No legal liability on the part of the Government for payment of any money beyond the end of each fiscal year (September 30) shall arise unless or until funds are made available to the Contracting Officer for this procurement and written notice of such availability is given to the Contractor. (End of clause) #### 552.232-74 Invoice Payments. As prescribed in 532.908(a)(1), insert the following clause: Invoice Payments (Sep 1999) (a) The due date for making invoice payments by the designated payment office is: (1) For orders placed electronically by the General Services Administration (GSA) Federal Supply Service (FSS), and to be paid by GSA through electronic funds transfer (EFT), the later of the following two events: (i) The 10th day after the designated billing office receives a proper invoice from the Contractor. If the designated billing office fails to annotate the invoice with the date of receipt at the time of receipt, the invoice payment due date shall be the 10th day after the date of the Contractor’s invoice; provided the Contractor submitted a proper invoice and no disagreement exists over quantity, quality, or Contractor compliance with contract requirements. (ii) The 10th day after Government acceptance of supplies delivered or services performed by the Contractor. (2) For all other orders, the later of the following two events: (i) The 30th day after the designated billing office receives a proper invoice from the Contractor. If the designated billing office fails to annotate the invoice with the date of receipt at the time of receipt, the invoice payment due date shall be the 30th day after the date of the Contractor’s invoice; provided the Contractor submitted a proper invoice and no disagreement exists over quantity, quality, or Contractor compliance with contract requirements. (ii) The 30th day after Government acceptance of supplies delivered or services performed by the Contractor. (3) On a final invoice, if the payment amount is subject to contract settlement actions, acceptance occurs on the effective date of the contract settlement. (b) The General Services Administration will issue payment on the due date in paragraph (a)(1) of this clause if the Contractor complies with full cycle electronic commerce. Full cycle electronic commerce includes all the following elements: (1) The Contractor must receive and fulfill electronic data interchange (EDI) purchase orders (transaction set 850). (2) The Contractor must generate and submit to the Government valid EDI invoices (transaction set 810) or submit invoices through the GSA Finance Center Internet-based invoice process. Internet-based invoices must be submitted using procedures provided by GSA. (3) The Contractor’s financial institution must receive and process, on behalf of the Contractor, EFT payments through the Automated Clearing House (ACH) system. (4) The EDI transaction sets in paragraphs (b)(1) through (b)(3) of this clause must adhere to implementation conventions provided by GSA. (c) If any of the conditions in paragraph (b) of this clause do not occur, the 10-day payment due dates in paragraph (a)(1) of this clause become 30-day payment due dates. (d) Notwithstanding paragraph (g) of the clause at FAR 52.212-4, Contract Terms and Conditions—Commercial Items, if the Contractor submits hard-copy invoices, submit only an original invoice. No copies of the invoice are required. (e) All other provisions of the Prompt Payment Act (31 U.S.C. 3901 et seq.) and Office of Management and Budget (OMB) Circular A- 125, Prompt Payment, apply. (End of clause) #### 552.232-75 Prompt Payment. As prescribed in 532.908(b)(1), insert the following clause: Prompt Payment (Sep 1999) The Government will make payments under the terms and conditions specified in this clause. Payment shall be considered as being made on the day a check is dated or an electronic funds transfer is made. All days referred to in this clause are calendar days, unless otherwise specified. (a) Payment due date. (1) Rental payments. Rent shall be paid monthly in arrears and will be due on the first workday of each month, and only as provided for by the lease. (i) When the date for commencement of rent falls on the 15th day of the month or earlier, the initial monthly rental payment under this contract shall become due on the first workday of the month following the month in which the commencement of the rent is effective. (ii) When the date for commencement of rent falls after the 15th day of the month, the initial monthly rental payment under this contract shall become due on the first workday of the second month following the month in which the commencement of the rent is effective. (2) Other payments. The due date for making payments other than rent shall be the later of the following two events: (i) The 30th day after the designated billing office has received a proper invoice from the Contractor. (ii) The 30th day after Government acceptance of the work or service. However, if the designated billing office fails to annotate the invoice with the actual date of receipt, the invoice payment due date shall be deemed to be the 30th day after the Contractor’s invoice is dated, provided a proper invoice is received and there is no disagreement over quantity, quality, or Contractor compliance with contract requirements. (b) Invoice and inspection requirements for payments other than rent. (1) The Contractor shall prepare and submit an invoice to the designated billing office after completion of the work. A proper invoice shall include the following items: (i) Name and address of the Contractor. (ii) Invoice date. (iii) Lease number. (iv) Government’s order number or other authorization. (v) Description, price, and quantity of work or services delivered. (vi) Name and address of Contractor official to whom payment is to be sent (must be the same as that in the remittance address in the lease or the order). (vii) Name (where practicable), title, phone number, and mailing address of person to be notified in the event of a defective invoice. (2) The Government will inspect and determine the acceptability of the work performed or services delivered within 7 days after the receipt of a proper invoice or notification of completion of the work or services unless a different period is specified at the time the order is placed. If actual acceptance occurs later, for the purpose of determining the payment due date and calculation of interest, acceptance will be deemed to occur on the last day of the 7 day inspection period. If the work or service is rejected for failure to conform to the technical requirements of the contract, the 7 days will be counted beginning with receipt of a new invoice or notification. In either case, the Contractor is not entitled to any payment or interest unless actual acceptance by the Government occurs. (c) Interest Penalty. (1) An interest penalty shall be paid automatically by the Government, without request from the Contractor, if payment is not made by the due date. (2) The interest penalty shall be at the rate established by the Secretary of the Treasury under Section 12 of the Contract Disputes Act of 1978 (41 U.S.C. 611) that is in effect on the day after the due date. This rate is referred to as the “Renegotiation Board Interest Rate,” and it is published in the Federal Register semiannually on or about January 1 and July 1. The interest penalty shall accrue daily on the payment amount approved by the Government and be compounded in 30-day increments inclusive from the first day after the due date through the payment date. (3) Interest penalties will not continue to accrue after the filing of a claim for such penalties under the clause at 52.233-1, Disputes, or for more than 1 year. Interest penalties of less than $1.00 need not be paid. (4) Interest penalties are not required on payment delays due to disagreement between the Government and Contractor over the payment amount or other issues involving contract compliance or on amounts temporarily withheld or retained in accordance with the terms of the contract. Claims involving disputes, and any interest that may be payable, will be resolved in accordance with the clause at 52.233-1, Disputes. (End of clause) Alternate I (Sep 1999). If Alternate I is used, subparagraph (a)(1) of the basic clause should be designated as paragraph (a) and subparagraph (a)(2) and paragraph (b) should be deleted. Paragraph (c) of the basic clause should be redesignated (b). #### 552.232-76 Electronic Funds Transfer Payment. As prescribed in 532.908(b)(2), insert the following clause: Electronic Funds Transfer Payment (Mar 2000) (a) The Government will make payments under this lease by electronic funds transfer (EFT). The Lessor must, no later than 30 days before the first payment: (1) Designate a financial institution for receipt of EFT payments. (2) Submit this designation to the Contracting Officer or other Government official, as directed. (b) The Lessor must provide the following information: (1) The American Bankers Association 9-digit identifying number for Automated Clearing House (ACH) transfers of the financing institution receiving payment if the institution has access to the Federal Reserve Communications System. (2) Number of account to which funds are to be deposited. (3) Type of depositor account (“C” for checking, “S” for savings). (4) If the Lessor is a new enrollee to the EFT system, the Lessor must complete and submit a “Payment Information Form,” SF 3881, before payment can be processed. (c) If the Lessor, during the performance of this contract, elects to designate a different financial institution for the receipt of any payment, the appropriate Government official must receive notice of such change and the required information specified above no later than 30 days before the date such change is to become effective. (d) The documents furnishing the information required in this clause must be dated and contain the: (1) Signature, title, and telephone number of the Lessor or the Lessor’s authorized representative. (2) Lessor’s name. (3) Lease number. (e) Lessor’s failure to properly designate a financial institution or to provide appropriate payee bank account information may delay payments of amounts otherwise properly due. (End of clause) #### 552.232-77 Payment By Governmentwide Commercial Purchase Card. As prescribed in 532.7003, insert the following clause: Payment by Governmentwide Commercial Purchase Card (Mar 2000) (a) Definitions. “Governmentwide commercial purchase card” means a uniquely numbered credit card issued by a contractor under GSA’s Governmentwide Contract for Fleet, Travel, and Purchase Card Services to named individual Government employees or entities to pay for official Government purchases. “Oral order” means an order placed orally either in person or by telephone. (b) At the option of the Government and if agreeable to the Contractor, payments of * or less for oral or written orders may be made using the Governmentwide commercial purchase card. (c) The Contractor shall not process a transaction for payment through the credit card clearinghouse until the purchased supplies have been shipped or services performed. Unless the cardholder requests correction or replacement of a defective or faulty item under other contract requirements, the Contractor must immediately credit a cardholder’s account for items returned as defective or faulty. (d) Payments made using the Governmentwide commercial purchase card are not eligible for any negotiated prompt payment discount. Payment made using a Government debit card will receive the applicable prompt payment discount. (End of clause) *Enter amount not to exceed $100,000. Alternate I (Mar 2000). For FSS schedule solicitations and contracts, replace paragraph (b) of the basic clause and add paragraph (c) as follows. Redesignate paragraphs (c) and (d) of the basic clause as (d) and (e) respectively. (b) The Contractor must accept the Governmentwide commercial purchase card for payments equal to or less than the micro-purchase threshold (see Federal Acquisition Regulation 2.101) for oral or written orders under this contract. (c) The Contractor and the ordering agency may agree to use the Governmentwide commercial purchase card for dollar amounts over the micro-purchase threshold, and the Government encourages the Contractor to accept payment by the purchase card. The dollar value of a purchase card action must not exceed the ordering agency’s established limit. If the Contractor will not accept payment by the purchase card for an order exceeding the micro-purchase threshold, the Contractor must so advise the ordering agency within 24 hours of receipt of the order. #### 552.232-78 Payment Information. As prescribed in 532.908(c), insert the following clause: Payment Information (Jul 2000) The General Services Administration (GSA) makes information on contract payments available electronically at http://www.finance.gsa.gov. The Contractor may register at the site and review its record of payments. This site provides information only on payments made by GSA, not by other agencies. (End of clause) #### 552.232-79 Payment by Credit Card. As prescribed in 532.7003(c) insert the following clause: Payment by Credit Card (May 2003) (a) Definitions. “Credit card” means any credit card used to pay for purchases, including the Governmentwide Commercial Purchase Card. “Governmentwide commercial purchase card” means a uniquely numbered credit card issued by a Contractor under GSA’s Governmentwide Contract for Fleet, Travel, and Purchase Card Services to named individual Government employees or entities to pay for official Government purchases. “Oral order” means an order placed orally either in person or by telephone. (b) The Contractor must accept the credit card for payments equal to or less than the micro-purchase threshold (see Federal Acquisition Regulation 2.101) for oral or written orders under this contract. (c) The Contractor and the ordering agency may agree to use the credit card for dollar amounts over the micro-purchase threshold, and the Government encourages the Contractor to accept payment by the purchase card. The dollar value of a purchase card action must not exceed the ordering agency’s established limit. If the Contractor will not accept payment by the purchase card for an order exceeding the micro-purchase threshold, the Contractor must so advise the ordering agency within 24 hours of receipt of the order. (d) The Contractor shall not process a transaction for payment through the credit card clearinghouse until the purchased supplies have been shipped or services performed. Unless the cardholder requests correction or replacement of a defective or faulty item under other contract requirements, the Contractor must immediately credit a cardholder’s account for items returned as defective or faulty. (e) Payments made using the Governmentwide commercial purchase card are not eligible for any negotiated prompt payment discount. Payment made using an ordering activity debit card will receive the applicable prompt payment discount. (End of clause) #### 552.232-81 Payments by Non-Federal Ordering Activities. As prescribed in 532.206(b), insert the following clause: Payments by Non-Federal Ordering Activities (May 2003) If eligible non-federal ordering activities are subject to a State prompt payment law, the terms and conditions of the applicable State law apply to the orders placed under this contract by such activities. If eligible non-federal ordering activities are not subject to a State prompt payment law, the terms and conditions of the Federal Prompt Payment Act as reflected in Federal Acquisition Regulation clause 52.232-25, Prompt Payment, or 52.212-4, Contract Terms and Conditions—Commercial Items, apply to such activities in the same manner as to Federal ordering activities. (End of clause) #### 552.232-82 Contractor’s Remittance (Payment) Address. As prescribed in 532.206(c), insert the following provision: Contractor’s Remittance (Payment) Address (May 2003) (a) Payment by electronic funds transfer (EFT) is the preferred method of payment. However, under certain conditions, the ordering activity may elect to make payment by check. The offeror shall indicate below the payment address to which checks should be mailed for payment of proper invoices submitted under a resultant contract.
Payment Address: |
(b) Offeror shall furnish by attachment to this solicitation, the remittance (payment) addresses of all authorized participating dealers receiving orders and accepting payment by check in the name of the Contractor in care of the dealer, if different from their ordering address(es) specified elsewhere in this solicitation. If a dealer’s ordering and remittance address differ, both must be furnished and identified as such. (c) All offerors are cautioned that if the remittance (payment) address shown on an actual invoice differs from that shown in paragraph (b) of this provision or on the attachment, the remittance address(es) in paragraph (b) of this provision or attached will govern. Payment to any other address, except as provided for through EFT payment methods, will require an administrative change to the contract. NOTE: All orders placed against a Federal Supply Schedule contract are to be paid by the individual ordering activity placing the order. Each order will cite the appropriate ordering activity payment address, and proper invoices should be sent to that address. Proper invoices should be sent to GSA only for orders placed by GSA. Any other ordering activity’s invoices sent to GSA will only delay your payment. (End of provision) #### 552.232-83 Contractor’s Billing Responsibilities. As prescribed in 532.206(d), insert the following clause: Contractor’s Billing Responsibilities (May 2003) The Contractor is required to perform all billings made pursuant to this contract. However, if the Contractor has dealers that participate on the contract and the billing/payment process by the Contractor for sales made by the dealer is a significant administrative burden, the following alternative procedures may be used. Where dealers are allowed by the Contractor to bill ordering activities and accept payment in the Contractor’s name, the Contractor agrees to obtain from all dealers participating in the performance of the contract a written agreement, which will require dealers to— (1) Comply with the same terms and conditions regarding prices as the Contractor for sales made under the contract; (2) Maintain a system of reporting sales under the contract to the manufacturer, which includes— (i) The date of sale; (ii) The ordering activity to which the sale was made; (iii) The service or product/model sold; (iv) The quantity of each service or product/model sold; (v) The price at which it was sold, including discounts; and (vi) All other significant sales data. (3) Be subject to audit by the Government, with respect to sales made under the contract; and (4) Place orders and accept payments in the name of the Contractor in care of the dealer. An agreement between a Contractor and its dealers pursuant to this procedure will not establish privity of contract between dealers and the Government. (End of clause) #### 552.236-70 Definitions. As prescribed in 536.570-1, insert the following clause: Definitions (Apr 1984) The terms “Administration” and “Service” as used in this contract shall mean the General Services Administration (GSA) and the Public Buildings Service (PBS), respectively. (End of clause) #### 552.236-71 Authorities and Limitations. As prescribed in 536.570-2, insert the following clause: Authorities and Limitations (Apr 1984) (a) All work shall be performed under the general direction of the Contracting Officer, who alone shall have the power to bind the Government and to exercise the rights, responsibilities, authorities and functions vested in him by the contract documents, except that he shall have the right to designate authorized representatives to act for him. Wherever any provision in this contract specifies an individual (such as, but not limited to, Construction Engineer, Resident Engineer, Inspector or Custodian) or organization, whether Governmental or private, to perform any act on behalf of or in the interests of the Government, that individual or organization shall be deemed to be the Contracting Officer’s authorized representative under this contract but only to the extent so specified. The Contracting Officer may, at any time during the performance of this contract, vest in any such authorized representatives additional power and authority to act for him or designate additional representatives, specifying the extent of their authority to act for him; a copy of each document vesting additional authority in an authorized representative or designating an additional authorized representative shall be furnished to the Contractor. (b) The Contractor shall perform the contract in accordance with any order (including but not limited to instruction, direction, interpretation, or determination) issued by an authorized representative in accordance with his authority to act for the Contracting Officer; but the Contractor assumes all the risk and consequences of performing the contract in accordance with any order (including but not limited to instruction, direction, interpretation, or determination) issued by an authorized representative in accordance with his authority to act for the ion) of anyone not authorized to issue such order. (End of clause) #### 552.236-72 Specialist. As prescribed in 536.570-3, insert the following clause: Specialist (Apr 1984) The term “Specialist,” as used in the contract specification, shall mean an individual or firm of established reputation (or, if newly organized, whose personnel have previously established a reputation in the same field), which is regularly engaged in, and which maintains a regular force of workmen skilled in either (as applicable) manufacturing or fabricating items required by the contract, installing items required by the contract, or otherwise performing work required by the contract. Where the contract specification requires installation by a specialist, that term shall also be deemed to mean either the manufacturer of the item, an individual or firm licensed by the manufacturer, or an individual or firm who will perform the work under the manufacturer’s direct supervision. (End of clause) #### 552.236-73 Basis of Award—Construction Contract. As prescribed in 536.570-4, insert the following provision or the appropriate Alternate: Basis of Award—Construction Contract (Apr 1985) (a) The low bidder for purposes of award is the responsible bidder offering the lowest price for the base bid (consisting of the lump sum bid and any associated unit price bids extended by the applicable number of units shown on the bid form). See Standard Form 1442, Solicitation, Offer, and Award and the provision entitled “Contract Award—Sealed Bidding.” (b) A bid may be rejected as nonresponsive if the bid is materially unbalanced as to bid prices. A bid is unbalanced when the bid is based on prices significantly less than cost for some work and significantly overstated for other work. (End of provision) Alternate I (Apr 1985). If the solicitation includes a base bid and options, the Contracting Officer shall delete paragraph (a) of the basic provision and insert paragraph (a) substantially as follows: (a) The low bidder for purposes of award is the responsible bidder offering the lowest aggregate price for (1) the base bid (consisting of the lump sum bid and any associated unit price bids extended by the applicable number of units shown on the bid form) plus (2) all options designated to be evaluated. The evaluation of options will not obligate the Government to exercise the options. See Standard Form 1442, Solicitation, Offer, and Award and the provision entitled “Contract Award—Sealed Bidding.” Alternate II (Apr 1985). If the solicitation includes a base bid and alternates, the Contracting Officer shall delete paragraph (a) of the basic provision and insert paragraphs (a), (c), and (d) substantially as follows: (a) The low bidder for purposes of award is the responsible bidder offering the lowest aggregate price for (1) the base bid (consisting of the lump sum bid and any associated unit price bids extended by the applicable number of units shown on the bid form) plus (2) those alternates in the order of priority listed in the solicitation that provide the most features of work within the funds available at bid opening. See the provision entitled “Contract Award—Sealed Bidding.” (c) Alternates will be added to the base bid in the order listed in the solicitation (see Standard Form 1442, Solicitation, Offer, and Award). If the addition of an alternate would make all bids exceed the funds available at bid opening, that alternate shall be skipped and the next subsequent alternate in a lower amount shall be added, provided that the aggregate of base bid and the selected alternates do not exceed the funds available at bid opening. For example, when the amount available is $100,000 and a bidder’s base bid is $85,000, with its separate bids on four successive alternates being $10,000, $8,000, $6,000, and $4,000, the aggregate amount of the bid for purposes of selecting the alternates would be $99,000 (base bid plus the first and fourth alternates). The second and third alternates are skipped because each of them would cause the aggregate of the base bid and alternates to exceed the $100,000 amount available when considered with the first alternate. All bids shall be evaluated on the basis of the same alternates. (d) After the low bidder has been determined in accordance with paragraph (a), an award may be made to that low bidder on the base bid, plus any combination of alternates for which funds are available at the time of award, but only if the award amount does not exceed the amount offered by any other responsible bidder. If the base bid plus the proposed combination of alternates exceed the amount offered by any other responsible bidder for the same combination of alternates, the award cannot be made on that combination of alternates. Alternate III (Apr 1985). If the solicitation includes a base bid, alternates, and options, the Contracting Officer shall delete paragraph (a) of the basic provision and insert paragraphs (a), (c), and (d) substantially as follows: (a) The low bidder for purposes of award is the responsible bidder offering the lowest aggregate price for (1) the base bid (consisting of the lump sum bid and any associated unit price bids extended by the applicable number of units shown on the bid form) plus (2) those alternates in the order of priority listed in the solicitation that provide the most features of work within the funds available at bid opening plus (3) all options designated to be evaluated except those options associated with alternates which are skipped during the selection process outlined in paragraph (c) of this provision. The evaluation of options will not obligate the Government to exercise the options. See the provision entitled “Contract Award—Sealed Bidding.” (c) Alternates will be added to the base bid in the order listed in the solicitation (see Standard Form 1442, Solicitation, Offer, or Award). If the addition of an alternate would make all bids exceed the funds available at bid opening, that alternate shall be skipped and the next subsequent alternate in a lower amount shall be added, provided that the aggregate of base bid and the selected alternates do not exceed the funds available at bid opening. For example, when the amount available is $100,000 and a bidder’s base bid is $85,000, with its separate bids on four successive alternates being $10,000, $8,000, $6,000, and $4,000, the aggregate amount of the bid for purposes of selecting the alternates would be $99,000 (base bid plus the first and fourth alternates). The second and third alternates are skipped because each of them would cause the aggregate of the base bid and alternates to exceed the $100,000 amount available when considered with the first alternate. All bids shall be evaluated on the basis of the same alternates. (d) After the low bidder has been determined in accordance with paragraph (a), award may be made to that low bidder on the base bid and evaluated options plus any combination of alternates for which funds are available at the time of award, but only if that low bidder is still low on the sum thereof plus any previously unevaluated options designated to be evaluated which are associated with proposed alternates that were skipped during the selection under paragraph (c) of this provision. If that low bidder is not still low, award cannot be made on the proposed combination of alternates. #### 552.236-74 Working hours. As prescribed in 536.570-5, insert the following clause: Working Hours (Apr 1984) (a) It is contemplated that all work will be performed during the customary working hours of the trades involved unless otherwise specified in this contract. Work performed by the Contractor at his own volition outside such customary working hours shall be at no additional expense to the Government. (b) Any requests received by the Contractor from occupants of existing buildings to change the hours of work shall be referred to the Contracting Officer for determination. (End of clause) #### 552.236-75 Use of Premises. As prescribed in 536.570-6, insert the following clause: Use of Premises (Apr 1984) (a) If the premises are occupied, the Contractor, his subcontractors, and their employees shall comply with the regulations governing access to, operation of, and conduct while in or on the premises and shall perform the work required under this contract in such a manner as not to unreasonably interrupt or interfere with the conduct of Government business. (b) Any request received by the Contractor from occupants of existing buildings to change the sequence of work shall be referred to the Contracting Officer for determination. (c) If the premises are occupied, the Contractor, his subcontractors and their employees shall not have access to or be admitted into any building outside the scope of this contract except with official permission. (End of clause) #### 552.236-76 Measurements. As prescribed in 536.570-7, insert the following clause: Measurements (Apr 1984) All dimensions shown of existing work and all dimensions required for work that is to connect with work now in place, shall be verified by the Contractor by actual measurement of the existing work. Any discrepancies between the contract requirements and the existing conditions shall be referred to the Contracting Officer before any work affected thereby has been performed. (End of clause) #### 552.236-77 Specifications and Drawings. As prescribed in 536.570-8, insert the following clause: Specifications and Drawings (Sep 1999) The requirements of the clause entitled “Specifications and Drawings for Construction” at FAR 52.236-21, are supplemented as follows: (a) In case of difference between small and large-scale drawings, the large-scale drawings shall govern. Schedules on any contract drawing shall take precedence over conflicting information on that or any other contract drawing. On any of the drawings where a portion of the work is detailed or drawn out and the remainder is shown in outline, the parts detailed or drawn out shall apply also to all other like portions of the work. (b) Where the word “similar” occurs on the drawings, it shall have a general meaning and not be interpreted as being identical, and all details shall be worked out in relation to their location and their connection with other parts of the work. (c) Standard Details or Specification Drawings are applicable when listed, bound with the specifications, noted on the drawings or referenced elsewhere in the specifications. Where the notes on the drawings indicate modifications, such modifications shall govern. (d) In case of difference between Standard Details or Specification Drawings and the specifications, the specifications will govern. In case of difference between the Standard Details or Specification Drawings and the drawings prepared specifically for this contract, the later shall govern. (End of clause) #### 552.236-78 Shop Drawings, Coordination Drawings, and Schedules. As prescribed in 536.570-9, insert the following clause: Shop Drawings, Coordination Drawings, and Schedules (Sep 1999) The requirements, of the clause entitled “Specifications and Drawings for Construction” at FAR 52.236-21, are supplemented as follows: (a) The Contractor shall submit shop drawings, coordination drawings, and schedules for approval as required by the specifications or requested by the Contracting Officer as follows: (b) Shop drawings shall include fabrication, erection and setting drawings, schedule drawings, manufacturers’ scale drawings, wiring and control diagrams, cuts or entire catalogs, pamphlets, descriptive literature, and performance and test data. (c) Drawings and schedules, other than catalogs, pamphlets and similar printed material, shall be submitted in reproducible form with two prints made by a process approved by the Contracting Officer. Upon approval, the reproducible form will be returned to the Contractor who shall then furnish the number of additional prints, not to exceed 10, required by the specifications. The Contractor shall submit shop drawings in catalog, pamphlet and similar printed form in a minimum of four copies plus as many additional copies as the Contractor may desire or need for his use or use by subcontractors. (d) Before submitting shop drawings on the mechanical and electrical work, the Contractor shall submit and obtain the Contracting Officer’s approval of such lists of mechanical and electrical equipment and materials as may be required by the specifications. (e) Each shop drawing or coordination drawing shall have a blank area 5 by 5 inches, located adjacent to the title block. The title block shall display the following: Number and title of drawing Date of drawing or revision Name of project building or facility Name of Contractor and (if appropriate) name of subcontractor submitting drawing Clear identity of contents and location on the work Project title and contract number (f) Unless otherwise provided in this contract, or otherwise directed by the Contracting Officer, shop drawings, coordination drawings and schedules shall be submitted to the Contracting Officer, with a letter in triplicate, sufficiently in advance of construction requirements to permit no less than 10 working days for checking and appropriate action. (g) Approval of drawings and schedules will be general and shall not be construed as permitting any departure from the contract requirements, or as approving departures from full-size details furnished by the Contracting Officer. (End of clause) #### 552.236-79 Samples. As prescribed in 536.570-10, insert the following clause: Samples (Apr 1984) (a) After the award of the contract, the Contractor shall furnish for the approval of the Contracting Officer samples required by the specifications or by the Contracting Officer. Samples shall be delivered to the Contracting Officer or to the Architect as specified or as directed. The Contractor shall prepay all shipping charges on samples. Materials or equipment for which samples are required shall not be used in the work until approved in writing by the Contracting Officer. (b) Each sample shall have a label indicating: (1) Name of project building or facility, project title and contract number. (2) Name of Contractor and, if appropriate, name of subcontractor. (3) Identification of material or equipment with specification requirement. (4) Place of origin. (5) Name of producer and brand (if any). Samples of finished materials shall have additional markings that will identify them under the finish schedules. (c) The Contractor shall mail under separate cover a letter in triplicate submitting each shipment of samples and containing the information required in paragraph (b) of this clause. He shall enclose a copy of this letter with the shipment and send a copy to the Government representative on the project. Approval of a sample shall be only for the characteristics or use named in such approval and shall not be construed to change or modify any contract requirement. Substitutions will not be permitted unless they are approved in writing by the Contracting Officer. (d) Approved samples not destroyed in testing will be sent to the Government representative at the project. Approved samples of hardware in good condition will be marked for identification and may be used in the work. Materials and equipment, incorporated in the work shall match the approved samples. Other samples not destroyed in testing or not approved will be returned to the Contractor at his expense if so requested at time of submission. (e) Failure of any material to pass the specified tests will be sufficient cause for refusal to consider, under this contract, any further samples of the same brand or make of that material or equipment which previously has proved unsatisfactory in service. (f) Samples of various materials or equipment delivered on the site or in place may be taken by the Government representative for testing. Samples failing to meet contract requirements will automatically void previous approvals of the items tested. The Contractor shall replace such materials or equipment found not to have met contract requirements, or there shall be a proper adjustment of the contract price as determined by the Contracting Officer. (g) Unless otherwise specified, when tests are required only one test of each sample proposed for use will be made at the expense of the Government. Samples which do not meet specification requirements will be rejected. Testing of additional samples will be made by the Government at the expense of the Contractor. (End of clause) #### 552.236-80 Heat. As prescribed in 536.570-11, insert the following clause: Heat (Apr 1984) Unless otherwise specified or unless already provided by the Government the Contractor shall; (a) Provide heat, as necessary to protect all work, materials, and equipment against injury from dampness and cold; (b) Protect, cover and/or heat as may be necessary, to produce and maintain a temperature of not less than 50 degrees Fahrenheit (1) in the concrete during the placing, setting and curing of concrete, and (2) in the plaster during the application, setting and curing of plaster; and (c) Provide heat as necessary in the area where work is to be done to provide the minimum temperature recommended by the supplier or manufacturer of the material, but in no case less than 50 degrees Fahrenheit, for a period beginning 10 days before placing of interior finishes and finish materials and continuing until completion or beneficial occupancy of the area, whichever is earlier. (End of clause) #### 552.236-81 Use of Equipment by the Government. As prescribed in 536.570-12, insert the following clause: Use of Equipment by the Government (Apr 1984) (a) The Government may take over and operate, with Government employees, such equipment as is necessary for heating or cooling such areas of the building as require the service, as soon as the installation is sufficiently complete. (b) The Contracting Officer will advise the Contractor by letter, prior to the use of equipment, which items of equipment will be operated, and the date and time such operation will begin. (c) Government operation of equipment will not relieve the Contractor of the one-year guarantee on materials and workmanship elsewhere provided for in this contract. (d) The guarantee period, elsewhere provided for in this contract, for each piece of equipment shall be in accordance with the “Guarantees” clause of this contract. (End of clause) #### 552.236-82 Subcontracts. As prescribed in 536.570-13, insert the following clause: Subcontracts (Apr 1984) (a) Nothing contained in the contract shall be construed as creating any contractual relationship between any subcontractor and the Government. The divisions or sections of the specifications are not intended to control the Contractor in dividing the work among subcontractors, or to limit the work performed by any trade. (b) The Contractor shall be responsible to the Government for acts and omissions of his own employees and of subcontractors and their employees. He shall also be responsible for the coordination of the work of the trades, subcontractors and suppliers. (c) The Government will not undertake to settle any differences between or among the Contractor, subcontractors, or suppliers. (End of clause) #### 552.236-83 Requirement for a Project Labor Agreement. As prescribed in 536.570-14, insert a clause substantially the same as the following: Requirement for a Project Labor Agreement (Sep 1999) (a) Definition. “Project Labor Agreement” (PLA) means an agreement between the contractor, subcontractors, and the union(s) representing workers. Under a PLA, the contractor and subcontractors on a project and the union(s) agree on terms and conditions of employment for the project, establishing a framework for labor-management cooperation to advance the Government’s procurement interest in cost, efficiency, and quality. (b) The Contractor shall, after contract award, enter into a PLA for performance of [Insert project or contract name]. The PLA binds the Contractor and subcontractors of whatever tier engaged in onsite construction work. The PLA shall include all the following terms: (1) Guarantees against strikes, lockouts, and similar work disruptions. (2) Effective, prompt and mutually binding procedures for resolving labor disputes arising during the project. (3) Other mechanisms for labor-management cooperation on matters of mutual interest and concern, including productivity, quality of work, safety, and health. (4) The PLA shall fully conform to all applicable statutes, regulations, and Executive Orders. (c) Any PLA reached under this clause shall not change the terms of this contract or provide for any pricing adjustment by the Government. (d) The Government shall not participate in the negotiations of any PLA. (e) Nothing in this clause precludes contractors or subcontractors from competing for contracts or subcontracts on this project without discrimination based on union or non-union status. (End of clause) #### 552.237-70 Qualifications of Offerors. As prescribed in 537.110(a), insert the following provision: Qualifications of Offerors (June 2009) (a) Offers will be considered only from responsible organizations or individuals now or recently engaged in the performance of building service contracts comparable to those described in this solicitation. To determine an Offeror’s qualifications, the Offeror may be requested to furnish a narrative statement listing comparable contracts which it has performed; a general history of its operating organization; and its complete experience. An Offeror may also be required to furnish a statement of its financial resources; show that it has the ability to maintain a staff of regular employees adequate to ensure continuous performance of the work; and, demonstrate that its equipment and/or plant capacity for the work contemplated is sufficient, adequate, and suitable. (b) Competency in performing comparable building service contracts, demonstration of acceptable financial resources, personnel staffing, plant, equipment, and supply sources will be considered in determining whether an Offeror is responsible. (c) Prospective Offerors are advised that in evaluating these areas involving any small business concern(s), any negative determinations are subject to the Certificate of Competency procedures set forth in the Federal Acquisition Regulation. (End of provision) #### 552.237-71 Qualifications of Employees. As prescribed in 537.110(a), insert the following clause: Qualifications of Employees (May 1989) (a) The contracting officer or a designated representative may require the Contractor to remove any employee(s) from GSA controlled buildings or other real property should it be determined that the individual(s) is either unsuitable for security reasons or otherwise unfit to work on GSA controlled property. (b) The Contractor shall fill out and cause each of its employees performing work on the contract work to fill out, for submission to the Government, such forms as may be necessary for security or other reasons. Upon request of the Contracting Officer, the Contractor and its employees shall be fingerprinted. (c) Each employee of the Contractor shall be a citizen of the United States of America, or an alien who has been lawfully admitted for permanent residence as evidenced by Alien Registration Receipt Card Form I-151, or, who presents other evidence from the Immigration and Naturalization Service that employment will not affect his immigration status. (End of clause) #### 552.237-72 Prohibition Regarding “Quasi-Military Armed Forces.” As prescribed in 537.110(b), insert the following clause: Prohibition Regarding “Quasi-Military Armed Forces” (Sep 1999) The Contractor must not, during the term of this contract, offer for hire “Quasi-Military Armed Forces” within the meaning of the court decision in United States ex. rel. Weinberger v. Equifax, 557 F. 2d 456 (5th Cir., 1977). (End of clause) #### 552.237-73 Restriction on Disclosure of Information. As prescribed in 537.270, insert the following clause: Restriction on Disclosure of Information (June 2009) (a) The Contractor shall, in the performance of this contract, keep all information contained in source documents or other media furnished by the Government in the strictest confidence. The Contractor shall not publish or otherwise divulge such information in whole or in part, in any manner or form, nor authorize or permit others to do so. The Contractor shall take such reasonable measures as are necessary to restrict access to such information, while in the Contractor’s possession, to those employees needing such information to perform the work provided herein, i.e., on a “need to know” basis. The Contractor shall immediately notify, in writing, the Contracting Officer in the event that the Contractor determines or has reason to suspect a breach of this requirement. (b) The Contractor shall not disclose any information concerning the work under this contract to any persons or entity unless the Contractor obtains prior written approval from the Contracting Officer. (c) The Contractor shall insert the substance of this clause in any consultant agreement or subcontract under this contract. (d) Any unauthorized disclosure of information may result in termination of this contract for cause. (End of clause) #### 552.238-70 Identification of Electronic Office Equipment Providing Accessibility for the Handicapped. As prescribed in 538.273(a)(1), insert the following clause: Identification of Electronic Office Equipment Providing Accessibility for the Handicapped (Sep 1991) (a) Definitions. “Electronic office equipment accessibility” means the application/configuration of electronic office equipment (includes hardware, software and firmware) in a manner that accommodates the functional limitations of individuals with disabilities (i.e., handicapped individuals) so as to promote productivity and provide access to work related and/or public information resources. “Handicapped individuals” mean qualified individuals with impairments as cited in 29 CFR 1613.702(f) who can benefit from electronic office equipment accessibility. “Special peripheral” means a special needs aid that provides access to electronic equipment that is otherwise inaccessible to a handicapped individual. (b) The offeror is encouraged to identify in its offer, and include in any commercial catalogs and pricelists accepted by the Contracting Officer, office equipment, including any special peripheral, that will facilitate electronic office equipment accessibility for handicapped individuals. Identification should include the type of disability accommodated and how the users with that disability would be helped. (End of clause) #### 552.238-71 Submission and Distribution of Authorized FSS Schedule Pricelists. As prescribed in 538.273(a)(2), insert the following clause: Submission and Distribution of Authorized FSS Schedule Pricelists (Sep 1999) (a) Definition. For the purposes of this clause, the Mailing List is [Contracting officer shall insert either: “the list of addressees provided to the Contractor by the Contracting Officer” or “the Contractor's listing of its Federal Government customers”]. (b) The Contracting Officer will return one copy of the Authorized FSS Schedule Pricelist to the Contractor with the notification of contract award. (1) The Contractor shall provide to the GSA Contracting Officer: (i) Two paper copies of Authorized FSS Schedule Pricelist; and (ii) The Authorized FSS Schedule Pricelist on a common-use electronic medium. The Contracting Officer will provide detailed instructions for the electronic submission with the award notification. Some structured data entry in a prescribed format may be required. (2) The Contractor shall provide to each addressee on the mailing list either: (i) One paper copy of the Authorized FSS Schedule Price List; or (ii) A self-addressed, postage-paid envelope or postcard to be returned by addressees that want to receive a paper copy of the pricelist. The Contractor shall distribute price lists within 20 calendar days after receipt of returned requests. (3) The Contractor shall advise each addressee of the availability of pricelist information through the on-line Multiple Award Schedule electronic data base. (c) The Contractor shall make all of the distributions required in paragraph (c) at least 15 calendar days before the beginning of the contract period, or within 30 calendar days after receipt of the Contracting Officer’s approval for printing, whichever is later. (d) During the period of the contract, the Contractor shall provide one copy of its Authorized FSS Schedule Pricelist to any authorized schedule user, upon request. Use of the mailing list for any other purpose is not authorized. (End of clause) Alternate I (May 2003). As prescribed in 538.273(a)(2), substitute the following paragraph (a) for paragraph (a) of the basic clause: (a) Definition. For the purposes of this clause, the Mailing List is [Contracting officer shall insert either: “the list of addressees provided to the Contractor by the Contracting Officer” or “the Contractor's listing of its ordering activity customers”]. #### 552.238-72 Identification of Products that have Environmental Attributes. As prescribed in 538.273(a)(3), insert the following clause: Identification of Products that Have Environmental Attributes (Sep 2003) (a) Several laws, Executive orders, and Agency directives require Federal buyers to purchase products that are less harmful to the environment, when they are life cycle cost-effective (see FAR Subpart 23.7). The U.S. General Services Administration (GSA) requires contractors to highlight environmental products under Federal Supply Service schedule contracts in various communications media (e.g., publications and electronic formats). (b) Definitions. As used in this clause— “Energy-efficient product” means a product that— (1) Meets Department of Energy and Environmental Protection Agency criteria for use of the ENERGY STAR® trademark label; or (2) Is in the upper 25 percent of efficiency for all similar products as designated by the Department of Energy’s Federal Energy Management Program. “GSA Advantage!” is an on-line shopping mall and ordering system that provides customers with access to products and services under GSA contracts. “Other environmental attributes” refers to product characteristics that provide environmental benefits, excluding recovered materials and energy and water efficiency. Several examples of these characteristics are biodegradable, recyclable, reduced pollutants, ozone safe, and low volatile organic compounds (VOCs). “Post-consumer material” means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Post-consumer material is part of the broader category of “recovered material.” The Environmental Protection Agency (EPA) has developed a list of EPA-designated products in their Comprehensive Procurement Guidelines (CPGs) to provide Federal agencies with purchasing recommendations on specific products in a Recovered Materials Advisory Notice (RMAN). The RMAN contains recommended recovered and post-consumer material content levels for the specific products designated by EPA (40 CFR part 247 and http://www.epa.gov/cpg/). “Recovered materials” means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process (Executive Order 13101 and 42 U.S.C. 6903(19) and http://www.epa.gov/cpg/). For paper and paper products, see the definition at FAR 11.301 (42 U.S.C. 6962(h)). “Remanufactured” means factory rebuilt to original specifications. “Renewable energy” means energy produced by solar, wind, geothermal, and biomass power. “Renewable energy technology” means— (1) Technologies that use renewable energy to provide light, heat, cooling, or mechanical or electrical energy for use in facilities or other activities; or (2) The use of integrated whole-building designs that rely upon renewable energy resources, including passive solar design. (c) (1) The offeror must identify products that— (i) Are compliant with the recovered and post-consumer material content levels recommended in the Recovered Materials Advisory Notices (RMANs) for EPA-designated products in the CPG program (http://www.epa.gov/cpg/); (ii) Contain recovered materials that either do not meet the recommended levels in the RMANs or are not EPA-designated products in the CPG program (see FAR 23.401 and http://www.epa.gov/cpg/); (iii) Are energy-efficient, as defined by either ENERGY STAR® and/or FEMP’s designated top 25th percentile levels (see ENERGY STAR® at http://www.energystar.gov/ and FEMP at http://www.eere.energy.gov/femp/procurement/); (iv) Are water-efficient; (v) Use renewable energy technology; (vi) Are remanufactured; and (vii) Have other environmental attributes. (2) These identifications must be made in each of the offeror’s following mediums: (i) The offer itself. (ii) Printed commercial catalogs, brochures, and pricelists. (iii) Online product website. (iv) Electronic data submission for GSA Advantage! submitted via GSA’s Schedules Input Program (SIP) software or the Electronic Data Inter-change (EDI). Offerors can use the SIP or EDI methods to indicate environmental and other attributes for each product that are translated into respective icons in GSA Advantage!. (d) An offeror, in identifying an item with an environmental attribute, must possess evidence or rely on a reasonable basis to substantiate the claim (see 16 CFR part 260, Guides for the Use of Environmental Marketing Claims). The Government will accept an offeror’s claim of an item’s environmental attribute on the basis of— (1) Participation in a Federal agency sponsored program (e.g., the EPA and DOE ENERGY STAR® product labeling program); (2) Verification by an independent organization that specializes in certifying such claims; or (3) Possession of competent and reliable evidence. For any test, analysis, research, study, or other evidence to be “competent and reliable,” it must have been conducted and evaluated in an objective manner by persons qualified to do so, using procedures generally accepted in the profession to yield accurate and reliable results. (End of clause) #### 552.238-73 Cancellation As prescribed in 538.273(a)(4), insert the following clause: Cancellation (Sep 1999) Either party may cancel this contract in whole or in part by providing written notice. The cancellation will take effect 30 calendar days after the other party receives the notice of cancellation. If the Contractor elects to cancel this contract, the Government will not reimburse the minimum guarantee. (End of clause) #### 552.238-74 Industrial Funding Fee and Sales Reporting. As prescribed in 538.273(b)(1), insert the following clause: Industrial Funding Fee and Sales Reporting (Jul 2003) (a) Reporting of Federal Supply Schedule Sales. The Contractor shall report all contract sales under this contract as follows: (1) The Contractor shall accurately report the dollar value, in U.S. dollars and rounded to the nearest whole dollar, of all sales under this contract by calendar quarter (January 1–March 31, April 1–June 30, July 1–September 30, and October 1–December 31). The dollar value of a sale is the price paid by the Schedule user for products and services on a Schedule task or delivery order. The reported contract sales value shall include the Industrial Funding Fee (IFF). The Contractor shall maintain a consistent accounting method of sales reporting, based on the Contractor’s established commercial accounting practice. The acceptable points at which sales may be reported include— (i) Receipt of order; (ii) Shipment or delivery, as applicable; (iii) Issuance of an invoice; or (iv) Payment. (2) Contract sales shall be reported to FSS within 30 calendar days following the completion of each reporting quarter. The Contractor shall continue to furnish quarterly reports, including “zero” sales, through physical completion of the last outstanding task order or delivery order of the contract. (3) Reportable sales under the contract are those resulting from sales of contract items to authorized users unless the purchase was conducted pursuant to a separate contracting authority such as a Governmentwide Acquisition Contract (GWAC); a separately awarded FAR Part 12, FAR Part 13, FAR Part 14, or FAR Part 15 procurement; or a non-FAR contract. Sales made to state and local governments under Cooperative Purchasing authority shall be counted as reportable sales for IFF purposes. (4) The Contractor shall electronically report the quarterly dollar value of sales, including “zero” sales, by utilizing the automated reporting system at an Internet website designated by the General Services Administration (GSA)’s Federal Supply Service (FSS). Prior to using this automated system, the Contractor shall complete contract registration with the FSS Vendor Support Center (VSC). The website address, as well as registration instructions and reporting procedures, will be provided at the time of award. The Contractor shall report sales separately for each National Stock Number (NSN), Special Item Number (SIN), or sub-item. (5) The Contractor shall convert the total value of sales made in foreign currency to U.S. dollars using the “Treasury Reporting Rates of Exchange” issued by the U.S. Department of Treasury, Financial Management Service. The Contractor shall use the issue of the Treasury report in effect on the last day of the calendar quarter. The report is available from Financial Management Service, International Funds Branch, Telephone: (202) 874–7994, Internet: http://www.fms.treas.gov/intn.html. (b) The Contractor shall remit the IFF at the rate set by GSA’s FSS. (1) The Contractor shall remit the IFF to FSS in U.S. dollars within 30 calendar days after the end of the reporting quarter; final payment shall be remitted within 30 days after physical completion of the last outstanding task order or delivery order of the contract. (2) The IFF represents a percentage of the total quarterly sales reported. This percentage is set at the discretion of GSA’s FSS. GSA’s FSS has the unilateral right to change the percentage at any time, but not more than once per year. FSS will provide reasonable notice prior to the effective date of the change. The IFF reimburses FSS for the costs of operating the Federal Supply Schedules Program and recoups its operating costs from ordering activities. Offerors must include the IFF in their prices. The fee is included in the award price(s) and reflected in the total amount charged to ordering activities. FSS will post notice of the current IFF at http://72a.fss.gsa.gov/ or successor website as appropriate. (c) Within 60 days of award, an FSS representative will provide the Contractor with specific written procedural instructions on remitting the IFF. FSS reserves the unilateral right to change such instructions from time to time, following notification to the Contractor. (d) Failure to remit the full amount of the IFF within 30 calendar days after the end of the applicable reporting period constitutes a contract debt to the United States Government under the terms of FAR Subpart 32.6. The Government may exercise all rights under the Debt Collection Improvement Act of 1996, including withholding or setting off payments and interest on the debt (see FAR clause 52.232-17, Interest). Should the Contractor fail to submit the required sales reports, falsify them, or fail to timely pay the IFF, this is sufficient cause for the Government to terminate the contract for cause. (End of clause) #### 552.238-75 Price Reductions. As prescribed in 538.273(b)(2), insert the following clause: Price Reductions (May 2004) (a) Before award of a contract, the Contracting Officer and the Offeror will agree upon (1) the customer (or category of customers) which will be the basis of award, and (2) the Government’s price or discount relationship to the identified customer (or category of customers). This relationship shall be maintained throughout the contract period. Any change in the Contractor’s commercial pricing or discount arrangement applicable to the identified customer (or category of customers) which disturbs this relationship shall constitute a price reduction. (b) During the contract period, the Contractor shall report to the Contracting Officer all price reductions to the customer (or category of customers) that was the basis of award. The Contractor’s report shall include an explanation of the conditions under which the reductions were made. (c) (1) A price reduction shall apply to purchases under this contract if, after the date negotiations conclude, the Contractor— (i) Revises the commercial catalog, pricelist, schedule or other document upon which contract award was predicated to reduce prices; (ii) Grants more favorable discounts or terms and conditions than those contained in the commercial catalog, pricelist, schedule or other documents upon which contract award was predicated; or (iii) Grants special discounts to the customer (or category of customers) that formed the basis of award, and the change disturbs the price/discount relationship of the Government to the customer (or category of customers) that was the basis of award. (2) The Contractor shall offer the price reduction to the Government with the same effective date, and for the same time period, as extended to the commercial customer (or category of customers). (d) There shall be no price reduction for sales— (1) To commercial customers under firm, fixed-price definite quantity contracts with specified delivery in excess of the maximum order threshold specified in this contract; (2) To Federal agencies; (3) Made to State and local government entities when the order is placed under this contract (and the State and local government entity is the agreed upon customer or category of customer that is the basis of award); or (4) Caused by an error in quotation or billing, provided adequate documentation is furnished by the Contractor to the Contracting Officer. (e) The Contractor may offer the Contracting Officer a voluntary Governmentwide price reduction at any time during the contract period. (f) The Contractor shall notify the Contracting Officer of any price reduction subject to this clause as soon as possible, but not later than 15 calendar days after its effective date. (g) The contract will be modified to reflect any price reduction which becomes applicable in accordance with this clause. (End of clause) Alternate I (May 2003). As prescribed in 538.273(b)(2) substitute the following paragraph (c)(2) for paragraph (c)(2) of the basic clause, and substitute the following paragraph (d)(2) for paragraph (d)(2) of the basic clause. (c)(2) he Contractor shall offer the price reduction to the eligible ordering activities with the same effective date, and for the same time period, as extended to the commercial customer (or category of customers). (d)(2) To eligible ordering activities under this contract; or #### 552.238-76 Definition (Federal Supply Schedules)—Recovery Purchasing. As prescribed in 538.7104(a), insert the following clause: Definition (Federal Supply Schedules)—Recovery Purchasing (Feb 2007) Ordering activity (also called “ordering agency” and “ordering office”) means an eligible ordering activity (see (552.238-78, Alternate I) authorized to place orders under Federal Supply Schedule contracts. (End of clause) #### 552.238-77 Definition (Federal Supply Schedules). As prescribed in 538.7004(a), insert the following clause: Definition (Federal Supply Schedules) (May 2003) Ordering activity (also called “ordering agency” and “ordering office”) means an eligible ordering activity (see 552.238-78) authorized to place orders under Federal Supply Schedule contracts. (End of clause) #### 552.238-78 Scope of Contract (Eligible Ordering Activities). As prescribed in 538.7004(b) insert the following clause: Scope of Contract (Eligible Ordering Activities) (Sep 2008) (a) This solicitation is issued to establish contracts which may be used on a nonmandatory basis by the agencies and activities named below, as a source of supply for the supplies or services described herein, for domestic and/or overseas delivery. For Special Item Number 132-53, Wireless Services ONLY, limited geographic coverage (consistent with the Offeror's commercial practice) may be proposed. (1) Executive agencies (as defined in FAR Subpart 2.1) including nonappropriated fund activities as prescribed in 41 CFR 101-26.000; (2) Government contractors authorized in writing by a Federal agency pursuant to FAR 51.1; (3) Mixed ownership Government corporations (as defined in the Government Corporation Control Act); (4) Federal Agencies, including establishments in the legislative or judicial branch of government (except the Senate, the House of Representatives and the Architect of the Capitol and any activities under the direction of the Architect of the Capitol). (5) The District of Columbia; (6) Tribal governments when authorized under 25 USC 450j(k); (7) Qualified Nonprofit Agencies as authorized under 40 USC 502(b); and (8) Organizations, other than those identified in paragraph (d) of this clause, authorized by GSA pursuant to statute or regulation to use GSA as a source of supply. (b) Definitions. Domestic delivery is delivery within the 48 contiguous states, Alaska, Hawaii, Puerto Rico, Washington, DC, and U.S. territories. Domestic delivery also includes a port or consolidation point, within the aforementioned areas, for orders received from overseas activities. Overseas delivery is delivery to points outside of the 48 contiguous states, Washington, DC, Alaska, Hawaii, Puerto Rico, and U.S. territories. (c) Offerors are requested to check one of the following boxes: o Contractor will provide domestic and overseas delivery. o Contractor will provide overseas delivery only. o Contractor will provide domestic delivery only. (d) The following activities may place orders against Schedule 70 contracts, and Consolidated Schedule contracts containing information technology Special Item Numbers, and Schedule 84 contracts, on an optional basis; PROVIDED, the Contractor accepts order(s) from such activities: State and local government, includes any state, local, regional or tribal government or any instrumentality thereof (including any local educational agency or institution of higher learning). (e) Articles or services may be ordered from time to time in such quantities as may be needed to fill any requirement, subject to the Order Limitations thresholds which will be specified in resultant contracts. Overseas activities may place orders directly with schedule contractors for delivery to CONUS port or consolidation point. (f) (1) The Contractor is obligated to accept orders received from activities within the Executive branch of the Federal Government. (2) The Contractor is not obligated to accept orders received from activities outside the Executive branch; however, the Contractor is encouraged to accept such orders. If the Contractor elects to accept such orders, all provisions of the contract shall apply, including clause 552.232-79, Payment by Credit Card. If the Contractor is unwilling to accept such orders, and the proposed method of payment is not through the Credit Card, the Contractor shall return the order by mail or other means of delivery within 5 workdays from receipt. If the Contractor is unwilling to accept such orders, and the proposed method of payment is through the Credit Card, the Contractor must so advise the ordering activity within 24 hours of receipt of order. (Reference clause 552.232-79, Payment by Credit Card.) Failure to return an order or advise the ordering activity within the time frames of this paragraph shall constitute acceptance whereupon all provisions of the contract shall apply. (g) The Government is obligated to purchase under each resultant contract a guaranteed minimum of $2,500 (two thousand, five hundred dollars) during the contract term. (End of clause) Alternate I (Feb 2007). As prescribed in 538.7104(b), substitute the following paragraphs (a) and (d) for paragraphs (a) and (d) of the basic clause: (a) This solicitation is issued to establish contracts which may be used on a nonmandatory basis by the agencies and activities named below, as a source of supply for the supplies or services described herein, for domestic delivery. (1) Executive agencies (as defined in Federal Acquisition Regulation Subpart 2.1) including nonappropriated fund activities as prescribed in 41 CFR 101-26.000; (2) Government contractors authorized in writing by a Federal agency pursuant to Federal Acquisition Regulation Subpart 51.1; (3) Mixed ownership Government corporations (as defined in the Government Corporation Control Act); (4) Federal Agencies, including establishments in the legislative or judicial branch of government (except the Senate, the House of Representatives and the Architect of the Capitol and any activities under the direction of the Architect of the Capitol); (5) The District of Columbia; (6) Tribal governments when authorized under 25 U.S.C. 450j(k); (7) Qualified Nonprofit Agencies as authorized under 40 U.S.C. 502(b); and (8) Organizations, other than those identified in paragraph (d) of this clause, authorized by GSA pursuant to statute or regulation to use GSA as a source of supply. (d) The following activities may place orders against Federal Supply Schedules for products and services determined by the Secretary of Homeland Security to facilitate recovery from major disasters, terrorism, or nuclear, biological, chemical, or radiological attack, on an optional basis; PROVIDED, the Contractor accepts order(s) from such activities: State and local government entities, includes any state, local, regional or tribal government or any instrumentality thereof (including any local educational agency or institution of higher learning). “State and local government entities”, means the states of the United States, counties, municipalities, cities, towns, townships, tribal governments, public authorities (including public or Indian housing agencies under the United States Housing Act of 1937), school districts, colleges and other institutions of higher education, council of governments (incorporated or not), regional or interstate government entities, or any agency or instrumentality of the preceding entities (including any local educational agency or institution of higher education), and including legislative and judicial departments. The term does not include contractors of, or grantees of, State or local governments. (1) “Local educational agency” has the meaning given that term in section 8013 of the Elementary and Secondary Education Act of 1965 (20 U.S.C. 7713). (2) “Institution of higher education” has the meaning given that term in section 101(a) of the Higher Education Act of 1965 (20 U.S.C. 1001(a)). (3) “Tribal government” means— (i) The governing body of any Indian tribe, band, nation, or other organized group or community located in the continental United States (excluding the State of Alaska) that is recognized as eligible for the special programs and services provided by the United States to Indians because of their status as Indians; and (ii) Any Alaska Native regional or village corporation established pursuant to the Alaska Native Claims Settlement Act (43 U.S.C. 1601 et seq.). #### 552.238-79 Use of Federal Supply Schedule Contracts by Certain Entities—Cooperative Purchasing. As prescribed in 538.7004(c), insert the following clause: Use of Federal Supply Schedule Contracts by Certain Entities—Cooperative Purchasing (May 2004) (a) If an entity identified in paragraph (d) of the clause at 552.238-78, Scope of Contract (Eligible Ordering Activities), elects to place an order under this contract, the entity agrees that the order shall be subject to the following conditions: (1) When the Contractor accepts an order from such an entity, a separate contract is formed which incorporates by reference all the terms and conditions of the Schedule contract except the Disputes clause, the patent indemnity clause, and the portion of the Commercial Item Contract Terms and Conditions that specifies “Compliance with laws unique to Government contracts” (which applies only to contracts with entities of the Executive branch of the U.S. Government). The parties to this new contract which incorporates the terms and conditions of the Schedule contract are the individual ordering activity and the Contractor. The U.S. Government shall not be liable for the performance or nonperformance of the new contract. Disputes which cannot be resolved by the parties to the new contract may be litigated in any State or Federal court with jurisdiction over the parties, applying Federal procurement law, including statutes, regulations and case law, and, if pertinent, the Uniform Commercial Code. To the extent authorized by law, parties to this new contract are encouraged to resolve disputes through Alternative Dispute Resolution. Likewise, a Blanket Purchase Agreement (BPA), although not a contract, is an agreement that may be entered into by the Contractor with such an entity and the Federal Government is not a party. (2) Where contract clauses refer to action by a Contracting Officer or a Contracting Officer of GSA, that shall mean the individual responsible for placing the order for the ordering activity (e.g., FAR 52.212-4 at paragraph (f) and FSS clause I-FSS-249 B.) (3) As a condition of using this contract, eligible ordering activities agree to abide by all terms and conditions of the Schedule contract, except for those deleted clauses or portions of clauses mentioned in paragraph (a)(1) of this clause. Ordering activities may include terms and conditions required by statute, ordinance, regulation, order, or as otherwise allowed by State and local government entities as a part of a statement of work (SOW) or statement of objective (SOO) to the extent that these terms and conditions do not conflict with the terms and conditions of the Schedule contract. The ordering activity and the Contractor expressly acknowledge that, in entering into an agreement for the ordering activity to purchase goods or services from the Contractor, neither the ordering activity nor the Contractor will look to, primarily or in any secondary capacity, or file any claim against the United States or any of its agencies with respect to any failure of performance by the other party. (4) The ordering activity is responsible for all payments due the Contractor under the contract formed by acceptance of the ordering activity’s order, without recourse to the agency of the U.S. Government, which awarded the Schedule contract. (5) The Contractor is encouraged, but not obligated, to accept orders from such entities. The Contractor may, within 5 days of receipt of the order, decline to accept any order, for any reason. The Contractor shall fulfill orders placed by such entities, which are not declined within the 5-day period. (6) The supplies or services purchased will be used for governmental purposes only and will not be resold for personal use. Disposal of property acquired will be in accordance with the established procedures of the ordering activity for the disposal of personal property. (b) If the Schedule Contractor accepts an order from an entity identified in paragraph (d) of the clause at 552.238-78, Scope of Contract (Eligible Ordering Activities), the Contractor agrees to the following conditions: (1) The ordering activity is responsible for all payments due the Contractor for the contract formed by acceptance of the order, without recourse to the agency of the U.S. Government, which awarded the Schedule contract. (2) The Contractor is encouraged, but not obligated, to accept orders from such entities. The Contractor may, within 5 days of receipt of the order, decline to accept any order, for any reason. The Contractor shall decline the order using the same means as those used to place the order. The Contractor shall fulfill orders placed by such entities, which are not declined within the 5-day period. (c) In accordance with clause 552.238-74, Industrial Funding Fee and Sales Reporting, the Contractor must report the quarterly dollar value of all sales under this contract. When submitting sales reports, the Contractor must report two dollar values for each Special Item Number: (1) The dollar value for sales to entities identified in paragraph (a) of the clause at 552.238-78, Scope of Contract (Eligible Ordering Activities), and (2) The dollar value for sales to entities identified in paragraph (d) of clause 552.238-78. (End of clause) #### 552.238-80 Use of Federal Supply Schedule Contracts by Certain Entities–Recovery Purchasing. As prescribed in 538.7104(c), insert the following clause: Use of Federal Supply Schedule Contracts by Certain Entities—recovery Purchasing (Feb 2007) (a) If an entity identified in paragraph (d) of the clause at 552.238-78, Scope of Contract (Eligible Ordering Activities)–Alternate I, elects to place an order under this contract, the entity agrees that the order shall be subject to the following conditions: (1) When the Contractor accepts an order from such an entity, a separate contract is formed which incorporates by reference all the terms and conditions of the Schedule contract except the Disputes clause, the patent indemnity clause, and the portion of the Commercial Item Contract Terms and Conditions that specifies “Compliance with laws unique to Government contracts” (which applies only to contracts with entities of the Executive branch of the U.S. Government). The parties to this new contract which incorporates the terms and conditions of the Schedule contract are the individual ordering activity and the Contractor. The U.S. Government shall not be liable for the performance or nonperformance of the new contract. Disputes which cannot be resolved by the parties to the new contract may be litigated in any State or Federal court with jurisdiction over the parties, applying Federal procurement law, including statutes, regulations and case law, and, if pertinent, the Uniform Commercial Code. To the extent authorized by law, parties to this new contract are encouraged to resolve disputes through Alternative Dispute Resolution. Likewise, a Blanket Purchase Agreement (BPA), although not a contract, is an agreement that may be entered into by the Contractor with such an entity and the Federal Government is not a party. (2) Where contract clauses refer to action by a Contracting Officer or a Contracting Officer of GSA, that shall mean the individual responsible for placing the order for the ordering activity (e.g., Federal Acquisition Regulation 52.212-4 at paragraph (f) and FSS clause I-FSS-249 B). (3) As a condition of using this contract, eligible ordering activities agree to abide by all terms and conditions of the Schedule contract, except for those deleted clauses or portions of clauses mentioned in paragraph (a)(1) of this clause. Ordering activities may include terms and conditions required by statute, ordinance, regulation, order, or as otherwise allowed by State and local government entities as a part of a statement of work (SOW) or statement of objective (SOO) to the extent that these terms and conditions do not conflict with the terms and conditions of the Schedule contract. The ordering activity and the Contractor expressly acknowledge that, in entering into an agreement for the ordering activity to purchase goods or services from the Contractor, neither the ordering activity nor the Contractor will look to, primarily or in any secondary capacity, or file any claim against the United States or any of its agencies with respect to any failure of performance by the other party. (4) The ordering activity is responsible for all payments due the Contractor under the contract formed by acceptance of the ordering activity’s order, without recourse to the agency of the U.S. Government, which awarded the Schedule contract. (5) The Contractor is encouraged, but not obligated, to accept orders from such entities. The Contractor may, within 5 days of receipt of the order, decline to accept any order, for any reason. The Contractor shall fulfill orders placed by such entities, which are not declined within the 5-day period. (6) The supplies or services purchased will be used for governmental purposes only and will not be resold for personal use. Disposal of property acquired will be in accordance with the established procedures of the ordering activity for the disposal of personal property. (7) The state or local government ordering activity will be responsible for purchasing products or services to be used to facilitate recovery from a major disaster declared by the President under the Robert T. Stafford Disaster Relief and Emergency Assistance Act (42 U.S.C. 5121 et seq.) or to facilitate recovery from terrorism or nuclear, biological, chemical, or radiological attack. (b) If the Schedule Contractor accepts an order from an entity identified in paragraph (d) of the clause at 552.238-78, Scope of Contract (Eligible Ordering Activities) –Alternate I, the Contractor agrees to the following conditions— (1) The ordering activity is responsible for all payments due the Contractor for the contract formed by acceptance of the order, without recourse to the agency of the U.S. Government, which awarded the Schedule contract. (2) The Contractor is encouraged, but not obligated, to accept orders from such entities. The Contractor may, within 5 days of receipt of the order, decline to accept any order, for any reason. The Contractor shall decline the order using the same means as those used to place the order. The Contractor shall fulfill orders placed by such entities, which are not declined within the 5-day period. (c) In accordance with clause 552.238-74, Industrial Funding Fee and Sales Reporting, the Contractor must report the quarterly dollar value of all sales under this contract. When submitting sales reports, the Contractor must report two dollar values for each Special Item Number— (1) The dollar value for sales to entities identified in paragraph (a) of the clause at 552.238-78, Scope of Contract (Eligible Ordering Activities)–Alternate I; and (2) The dollar value for sales to entities identified in paragraph (d) of clause 552.238-78, Alternate I. (d) A listing of the Federal Supply Schedule contracts for the products and services available for disaster recovery purchasing is accessible in GSA’s Schedules e-Library at web site http://www.gsaelibrary.gsa.gov. Click on the link, “Disaster Recovery Purchasing, State and Local.” The participating Contractors and the products and services available for disaster recovery purchasing will be labeled with the Disaster Recovery Purchasing icon. (End of clause) #### 552.242-70 Status Report of Orders and Shipments. As prescribed in 542.1107, insert the following clause: Status Report of Orders and Shipments (Feb 2009) (a) The Contractor shall furnish to the Administrative Contracting Officer (ACO) a report covering orders received and shipments made during each calendar month of contract performance. The information required by the Government shall be reported on GSA Form 1678, Status Report of Orders and Shipments, in accordance with instructions on the form. The information required by the GSA Form 1678 may also be submitted in an automated printout form if authorized by the ACO. Alternatively, the required information may be reported by electronic data interchange using ANSI standards. For further information, contact GSA, Contract Administration Division [Insert appropriate telephone number of QVOC]. Reports shall be forwarded to the ACO no later than the seventh workday of the succeeding month. (b) A copy of GSA Form 1678 will be forwarded to the Contractor with the contract. Additional copies of the form, if needed, may be reproduced by the Contractor. (End of clause) #### 552.243-71 Equitable Adjustments. As prescribed in 543.205, insert the following clause: Equitable Adjustments (Jan 2009) (a) This clause governs the determination of equitable adjustments to which the Contractor may be entitled under the “Changes” clause prescribed by FAR 52.243-4, the “Differing Site Conditions” clause prescribed by FAR 52.236-2, and any other provision of this contract allowing entitlement to an equitable adjustment. This clause does not govern determination of the Contractor’s relief allowable under the “Suspension of Work” clause prescribed by FAR 52.242-14. (b) At the written request of the Contracting Officer, the Contractor shall submit a proposal, in accordance with the requirements set forth herein, for an equitable adjustment to the contract for changes or other conditions that may entitle a Contractor to an equitable adjustment. If the Contractor deems an oral or written order to be a change to the contract, it shall promptly submit to the Contracting Officer a proposal for equitable adjustment attributable to such deemed change. The proposal shall also conform to the requirements set forth herein. (c) The proposal shall be submitted within the time specified in the “Changes” clause, or such other time as may reasonably be required by the Contracting Officer. In the case of a proposal submitted based on the “Differing Site Conditions” clause, the notice requirement of that clause shall be met. (d) Proposals for equitable adjustments, including no cost requests for adjustment of the contract’s required completion date, shall include a detailed breakdown of the following elements, as applicable: (1) Direct Costs. (2) Markups. (3) Change to the time for completion specified in the contract. (e) Direct Costs. The Contractor shall separately identify each item of deleted and added work associated with the change or other condition giving rise to entitlement to an equitable adjustment, including increases or decreases to unchanged work impacted by the change. For each item of work so identified, the Contractor shall propose for itself and, if applicable, its first two tiers of subcontractors, the following direct costs: (1) Material cost broken down by trade, supplier, material description, quantity of material units, and unit cost (including all manufacturing burden associated with material fabrication and cost of delivery to site, unless separately itemized); (2) Labor cost broken down by trade, employer, occupation, quantity of labor hours, and burdened hourly labor rate, together with itemization of applied labor burdens (exclusive of employer’s overhead, profit, and any labor cost burdens carried in employer’s overhead rate); (3) Cost of equipment required to perform the work, identified with material to be placed or operation to be performed; (4) Cost of preparation and/or revision to shop drawings and other submittals with detail set forth in paragraphs (e)(1) and (e)(2) of this clause; (5) Delivery costs, if not included in material unit costs; (6) Time-related costs not separately identified as direct costs, and not included in the Contractor’s or subcontractors’ overhead rates, as specified in paragraph (g) of this clause; and (7) Other direct costs. (f) Marked-up costs of subcontractors below the second tier may be treated as other direct costs of a second tier subcontractor, unless the Contracting Officer requires a detailed breakdown under paragraph (i) of this clause. (g) Extensions of Time and Time-related Costs. The Contractor shall propose a daily rate for each firm’s time-related costs during the affected period, and, for each firm, the increase or decrease in the number of work days of performance attributable to the change or other condition giving rise to entitlement to an equitable adjustment, with supporting analysis. Entitlement to time and time-related costs shall be determined as follows: (1) Increases or decreases to a firm’s time-related costs shall be allowed only if such increase or decrease necessarily and exclusively results from the change or other condition giving rise to entitlement to an equitable adjustment. (2) The Contractor shall not be entitled to an extension of time or recovery of its own time-related costs except to the extent that such change or other condition necessarily and exclusively causes its duration of performance to extend beyond the completion date specified in the contract. (3) Costs may be characterized as time-related costs only if they are incurred solely to support performance of this contract and the increase or decrease in such costs is solely dependent upon the duration of a firm’s performance of work. (4) Costs may not be characterized as time-related costs if they are included in the calculation of a firm’s overhead rate. (5) Equitable adjustment of time and time-related costs shall not be allowed unless the analysis supporting the proposal complies with provisions specified elsewhere in this contract regarding the Contractor’s project schedule. (h) Markups. For each firm whose direct costs are separately identified in the proposal, the Contractor shall propose an overhead rate, profit rate, and where applicable, a bond rate and insurance rate. Markups shall be determined and applied as follows: (1) Overhead rates shall be negotiated, and may be subject to audit and adjustment. (2) Profit rates shall be negotiated, but shall not exceed ten percent, unless entitlement to a higher rate of profit may be demonstrated. (3) The Contractor and its subcontractor[s] shall not be allowed overhead or profit on the overhead or profit received by a subcontractor, except to the extent that the subcontractor’s costs are properly included in other direct costs as specified in paragraph (f) of this clause. (4) Overhead rates shall be applied to the direct costs of work performed by a firm, and shall not be allowed on the direct costs of work performed by a subcontractor to that firm at any tier except as set forth below in paragraphs (h)(6) and (h)(7) of this clause. (5) Profit rates shall be applied to the sum of a firm’s direct costs and the overhead allowed on the direct costs of work performed by that firm. (6) Overhead and profit shall be allowed on the direct costs of work performed by a subcontractor within two tiers of a firm at rates equal to only fifty percent of the overhead and profit rates negotiated pursuant to paragraphs (h)(1) and (h)(2) of this clause for that firm, but not in excess of ten percent when combined. (7) Overhead and profit shall not be allowed on the direct costs of a subcontractor more than two tiers below the firm claiming overhead and profit for subcontractor direct costs. (8) If changes to a Contractor’s or subcontractor’s bond or insurance premiums are computed as a percentage of the gross change in contract value, markups for bond and insurance shall be applied after all overhead and profit is applied. Bond and insurance rates shall not be applied if the associated costs are included in the calculation of a firm’s overhead rate. (9) No markup shall be applied to a firm’s costs other than those specified herein. (i) At the request of the Contracting Officer, the Contractor shall provide such other information as may be reasonably necessary to allow evaluation of the proposal. If the proposal includes significant costs incurred by a subcontractor below the second tier, the Contracting Officer may require the same detail for those costs as required for the first two tiers of subcontractors, and markups shall be applied to these subcontractor costs in accordance with paragraph (h). (j) Proposal Preparation Costs. If performed by the firm claiming them, proposal preparations costs shall be included in the labor hours proposed as direct costs. If performed by an outside consultant or law firm, proposal preparation costs shall be treated as other direct costs to the firm incurring them. Requests for proposal preparation costs shall include the following: (1) A copy of the contract or other documentation identifying the consultant or firm, the scope of the services performed, the manner in which the consultant or firm was to be compensated, and if compensation was paid on an hourly basis, the fully burdened and marked-up hourly rates for the services provided. (2) If compensation was paid on an hourly basis, documentation of the quantity of hours worked, including descriptions of the activities for which the hours were billed, and applicable rates. (3) Written proof of payment of the costs requested. The sufficiency of the proof shall be determined by the Contracting Officer. (k) Proposal preparation costs shall be allowed only if— (1) The nature and complexity of the change or other condition giving rise to entitlement to an equitable adjustment warrants estimating, scheduling, or other effort not reasonably foreseeable at the time of contract award; (2) Proposed costs are not included in a firm’s time-related costs or overhead rate; and (3) Proposed costs were incurred prior to a Contracting Officer’s unilateral determination of an equitable adjustment under the conditions set forth in paragraph (o), or were incurred prior to the time the request for equitable adjustment otherwise became a matter in dispute. (l) Proposed direct costs, markups, and proposal preparation costs shall be allowable in the determination of an equitable adjustment only if they are reasonable and otherwise consistent with the contract cost principles and procedures set forth in Part 31 of the Federal Acquisition Regulation (48 CFR part 31) in effect on the date of this contract. Characterization of costs as direct costs, time-related costs, or overhead costs must be consistent with the requesting firm’s accounting practices on other work under this contract and other contracts. (m) If the Contracting Officer determines that it is in the Government’s interest that the Contractor proceed with a change before negotiation of an equitable adjustment is completed, the Contracting Officer may order the Contractor to proceed on the basis of a unilateral modification to the contract increasing or decreasing the contract price by an amount to be determined later. Such increase or decrease shall not exceed the increase or decrease proposed by the Contractor. (n) If the parties cannot agree to an equitable adjustment, the Contracting Officer may determine the equitable adjustment unilaterally. (o) The Contractor shall not be entitled to any proposal preparation costs incurred subsequent to the date of a unilateral determination or denial of the request if the Contracting Officer issues a unilateral determination or denial under any of the following circumstances: (1) The Contractor fails to submit a proposal within the time required by this contract or such time as may reasonably be required by the Contracting Officer. (2) The Contractor fails to submit additional information requested by the Contracting Officer within the time reasonably required. (3) Agreement to an equitable adjustment cannot be reached within 60 days of submission of the Contractor’s proposal or receipt of additional requested information, despite the Contracting Officer’s diligent efforts to negotiate the equitable adjustment. (End of clause) #### 552.246-70 Source Inspection by Quality Approved Manufacturer. As prescribed in 546.302-70, insert the following clause: Source Inspection by Quality Approved Manufacturer (July 2009) (a) Inspection system and inspection facilities. (1) The inspection system maintained by the Contractor under the Inspection of Supplies—Fixed Price clause (FAR 52.246-2) of this contract shall be maintained throughout the contract period. Unless otherwise authorized in writing by the Contracting Officer, the Contractor shall comply with all requirements of editions in effect on the date of the solicitation of either Federal Standard 368 or the International Organization for Standardization (ISO) Standard 9001:2000 (Quality Management Systems—Requirements). A documented description of the inspection system shall be made available to the Government before contract award. At the sole discretion of the Contracting Officer, he/she may authorize in writing exceptions to the quality assurance standards identified above. The Contractor shall immediately notify the Administrative Contracting Officer (ACO) of any changes made in the inspection system during the contract period. As used herein, the term “inspection system” means the Contractor’s own facility or any other facility acceptable to the Government that will be used to perform inspections or tests of materials and components before incorporation into end articles and for inspection of such end articles before shipment. When the manufacturing plant is located outside of the United States, the Contractor shall arrange delivery of the items from a plant or warehouse located in the United States (including Puerto Rico and the U.S. Virgin Islands) equipped to perform all inspections and tests required by the contract or specifications to evidence conformance therewith, or shall arrange with a testing laboratory or other facility in the United States, acceptable to the Government, to perform the required inspections and tests. (2) In addition to the requirements in Federal Standard 368, ISO 9001:2000 or as otherwise approved by the Government, records shall include the date inspection and testing were performed. These records shall be available for (i) 3 years after final payment; or (ii) 4 years from the end of the Contractor’s fiscal year in which the record was created, whichever period expires first. (3) Offerors are required to specify, in the space provided elsewhere in this solicitation, the name and address of each manufacturing plant or other facility where supplies will be available for inspection, indicating the item number(s) to which each applies. (4) The Contractor shall provide the Administrative Contracting Officer ACO with the name(s) of the individual and an alternate responsible for the inspection system. In the event that the designated individual(s) becomes unavailable to oversee the inspection system, the Contractor, within 10 calendar days of such event, shall provide the ACO with the names of the replacement individual(s). (b) Inspection by the Contractor. The Contractor is required to demonstrate that the supplies in the shipment have been subject to and have passed all inspections and tests required by the contract and meet the requirements of the contract. (c) Inspection by Government personnel. (1) Although the Government will normally rely upon the Contractor’s representation as to the quality of supplies shipped, it reserves the right under the Inspection of Supplies—Fixed Price clause to inspect and test all supplies called for by this contract, before acceptance, at all times and places, including the point of manufacture. When the Government notifies the Contractor of its intent to inspect supplies before shipment, the Contractor shall notify or arrange for subcontractors to notify the designated GSA quality assurance office 7 workdays before the date when supplies will be ready for inspection. Shipment shall not be made until inspection by the Government is completed and shipment is authorized by the Government. (2) The offeror shall indicate, in the spaces provided below, the location(s) at which the supplies will be inspected or made available for inspection. INSPECTION POINT
ITEM NO(S) | NAME OF MANUFACTURER | NAME, ADDRESS (Including County), and | TELEPHONE NUMBER
--- | --- | --- | ---
____________ | ____________ | ____________ | ____________
____________ | ____________ | ____________ | ____________
____________ | ____________ | ____________ | ____________
NOTE: If additional space is needed, the offeror may furnish the requested information by an attachment to the offer. (3) During the contract period, a Government representative may periodically select samples of supplies produced under this contract for Government verification, inspection, and testing. Samples selected for testing will be disposed of as follows: Samples from an accepted lot, not damaged in the testing process, will be returned promptly to the Contractor after completion of tests. Samples damaged in the testing process will be disposed of as requested by the Contractor. Samples from a rejected lot will be returned to the Contractor or disposed of in a time and manner agreeable to both the Contractor and the Government. (d) Quality deficiencies. (1) Notwithstanding any other clause of this contract concerning the conclusiveness of acceptance by the Government, any supplies or production lots shipped under this contract found to be defective in material or workmanship, or otherwise not in conformity with the requirements of this contract within a period of * months after acceptance shall, at the Government’s option, be replaced, repaired, or otherwise corrected by the Contractor at no cost to the Government within 30 calendar days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice to replace or correct. The Contractor shall remove, at its own expense, supplies rejected or required to be replaced, repaired, or corrected. When the nature of the defect affects an entire batch or lot of supplies, and the Contracting Officer determines that correction can best be accomplished by retaining the nonconforming supplies, and reducing the contract price by an equitable amount under the circumstances, then the equitable price adjustment shall apply to the entire batch or lot of supplies from which the nonconforming item was taken. (2) The Contractor may be issued a Quality Deficiency Notice (QDN) if: (i) Supplies in process, shipped, or awaiting shipment to fill Government orders are found not to comply with contract requirements, or (ii) deficiencies in either plant quality or process controls are found. Upon receipt of a QDN, the Contractor shall take immediate corrective action and shall suspend shipment of the supplies covered by the QDN until such time as corrective action has been completed. The Contractor shall notify the Government representative, within 5 workdays, of the action plan or the corrective action taken. The Government may elect to verify the corrective action at the Contractor location(s). Shipments of nonconforming supplies will be returned at the Contractor’s expense and may constitute cause for termination of the contract. Delays due to the insurance of a QDN do not constitute excusable delay under the default clause of this contract. Failure to complete corrective action in a timely manner may result in termination of the contract. (3) This contract may be terminated for default if subsequent Government inspection discloses that plant quality or process controls are not being maintained, supplies that do not meet the requirements of the contract are being shipped, or if the contractor fails to comply with any other requirement of this clause. (e) Additional cost for inspection and testing. The Contractor shall be charged for any additional cost of inspection/testing or reinspecting/retesting supplies for the reasons stated in paragraph (e) of FAR 52.246-2, Inspection of Supplies-Fixed Price. When inspection or testing is performed by or under the direction of GSA, charges will be at the rate of $ * per man-hour or fraction thereof if the inspection is at a GSA distribution center; $ * per man-hour or fraction thereof, plus travel costs incurred, if the inspection is at any other location; and $ * per man-hour or fraction thereof for laboratory testing, except that when a testing facility other than a GSA laboratory performs all or part of the required tests, the Contractor shall be assessed the actual cost incurred by the Government as a result of testing at such facility. When inspection is performed by or under the direction of any agency other than GSA, the charges indicated above may be used, or the agency may assess the actual cost of performing the inspection and testing. (f) Responsibility for rejected supplies. When the Contractor fails to remove or provide instructions for the removal of rejected supplies under paragraph (d) of this clause, pursuant to the Contracting Officer’s instructions, the Contractor shall be liable for all costs incurred by the Government in taking such measures as are expedient to avoid unnecessary loss to the Contractor. In addition to the remedies provided in FAR 52.246-2, supplies may be— (1) Stored and charged against the Contractor’s account; (2) Reshipped to the Contractor at its expense (any additional expense incurred by the Government or the freight carrier caused by the refusal of the Contractor to accept their return shall also be charged against the Contractor’s account); (3) Sold to the highest bidder on the open market and the proceeds applied against the accumulated storage and other costs, including the cost of the sale; or (4) Otherwise disposed of by the Government. (g) Subcontracting requirements. The Contractor shall insert in any subcontracts the inspection or testing provisions set forth in paragraphs (a) through (d) of this clause and the Inspection of Supplies—Fixed Price clause of this contract. The Contractor shall be responsible for compliance by any subcontractor with the provisions set forth in paragraphs (a) through (d) of this clause and the Inspection of Supplies—Fixed Price clause. (End of clause) * Normally insert 12 months as the period during which defective or otherwise nonconforming supplies must be replaced. However, when the supplies being bought have a shelf life of less than 1 year, you should use the shelf-life period, or in the instance where you reasonably expect a longer period to be available, you should use the longer period. ** The rates to be inserted are established by the Commissioner of the Federal Acquisition Service or a designee. #### 552.246-71 Source Inspection by Government. As prescribed in 546.302-71, insert the following clause: Source Inspection by Government (June 2009) (a) Inspection by Government personnel. (1) Supplies to be furnished under this contract will be inspected at source by the Government before shipment from the manufacturing plant or other facility designated by the Contractor, unless the Contractor is otherwise notified in writing by the Contracting Officer or a designated representative. Notwithstanding the foregoing, the Government may perform any or all tests contained in the contract specifications at a Government facility without prior written notice by the Contracting Officer before release of the supplies for shipment. Samples sent to a Government testing facility will be disposed of as follows: Samples from an accepted lot, not damaged in the testing process, will be returned promptly to the Contractor after completion of tests. Samples damaged in the testing process will be disposed of as requested by the Contractor. Samples from a rejected lot will be returned to the Contractor or disposed of in a time and manner agreeable to both the Contractor and the Government. (2) Government inspection responsibility will be assigned to the GSA quality assurance office which has jurisdiction over the State in which the Contractor’s or subcontractor’s plant or other designated point for inspection is located. The Contractor shall notify or arrange for subcontractors to notify the designated GSA quality assurance office 7 workdays before the date when supplies will be ready for inspection. Shipment shall not be made until after inspection by the Government is completed and shipment is authorized by the Government. (b) Inspection and receiving reports. For each shipment, the Contractor shall be responsible for preparation and distribution of inspection documents as follows: (1) DD Form 250, Material Inspection and Receiving Report, or computer formatted equivalent for deliveries to military agencies; or (2) GSA Form 308, Notice of Inspection for deliveries to GSA or other civilian agencies. When required, the Contractor will be furnished a supply of GSA Form 308 and/or DD Form 250, and complete instructions for their preparation and distribution. (c) Inspection facilities. (1) The inspection system required to be maintained by the Contractor in accordance with FAR 52.246-2, Inspection of Supplies—Fixed Price, may be the Contractor’s own facilities or any other facilities acceptable to the Government. These facilities shall be utilized to perform all inspections and tests of materials and components before incorporation into end articles, and for the inspection of such end articles before shipment. The Government reserves the right to evaluate the acceptability and effectiveness of the Contractor’s inspection system before award and periodically during the contract period. (2) Offerors are required to specify, in the spaces provided elsewhere in the solicitation, the name and address of each manufacturing plant or other facility where supplies will be available for inspection, indicating the item number(s) to which each applies. (3) The Contractor shall deliver the items specified in this contract from a plant or warehouse located within the United States (including Puerto Rico and the the U.S. Virgin Islands) that is equipped to perform all inspections and tests required by this contract or specifications to evidence conformance therewith, or shall arrange with a testing laboratory or other facility in the United States, acceptable to the Government, to perform the required inspections and tests. (d) Availability of records. (1) In addition to any other requirement of this contract, the Contractor shall maintain records showing the following information for each order received under the contract: (i) Order number; (ii) Date order received by the Contractor; (iii) Quantity ordered; (iv) Date scheduled into production; (v) Batch or lot number, if applicable; (vi) Date inspected and/or tested; (vii) Date available for shipment; (viii) Date shipped or date service completed; and (ix) National Stock Number (NSN), or if none is provided in the contract, the applicable item number or other contractual identification. (2) These records should be maintained at the point of source inspection and shall be available to the Contracting Officer, or an authorized representative, for (i) 3 years after final payment; or (ii) 4 years from the end of the Contractor’s fiscal year in which the record was created, whichever period expires first. (e) Additional cost for inspection and testing. The Contractor will be charged for any additional cost for inspecting/testing or reinspection/ retesting supplies for the reasons stated in paragraph (e) of FAR 52.246-2, Inspection of Supplies—Fixed Price. When inspection or testing is performed by or under the direction of GSA, charges will be at the rate of $ * per man-hour or fraction thereof if the inspection is at a GSA distribution center; $ * per man-hour or fraction thereof, plus travel costs incurred, if the inspection is at any other location; and $ * per man-hour or fraction thereof for laboratory testing, except that when a testing facility other than a GSA laboratory performs all or part of the required tests, the Contractor shall be assessed the actual cost incurred by the Government as a result of testing at such facility. When inspection is performed by or under the direction of any agency other than GSA, the charges indicated above may be used, or the agency may assess the actual cost of performing the inspection and testing. (f) Responsibility for rejected supplies. When the Contractor fails to remove or provide instructions for the removal of rejected supplies under FAR 52.246-2(h) pursuant to the Contracting Officer’s instructions, the Contractor shall be liable for all costs incurred by the Government in taking such measures as are expedient to avoid unnecessary loss to the Contractor. In addition to the remedies provided in FAR 52.246-2, supplies may be— (1) Stored for the Contractor’s account; (2) Reshipped to the Contractor at its expense (any additional expense incurred by the Government or the freight carrier caused by the refusal of the Contractor to accept their return also shall be for the Contractor’s account); or (3) Sold to the highest bidder on the open market and the proceeds applied against the accumulated storage and other costs, including the cost of the sale. (End of clause) *The rates to be inserted are established by the Commissioner of the Federal Acquisition Service or a designee. #### 552.246-72 Final Inspection and Tests. As prescribed in 546.312, insert the following clause: Final Inspection and Tests (Sep 1999) The Contractor shall give written notice to the Contracting Officer at least 10 calendar days before the date the work will be completed and ready for final inspection and tests. Final inspection and tests will begin within 10 calendar days after the date specified in the Contractor’s notice unless the Contracting Officer determines that the work is not ready for final inspection and so informs the Contractor. (End of clause) #### 552.246-77 Additional Contract Warranty Provisions for Supplies of a Noncomplex Nature. As prescribed in 546.710, insert the following clause in solicitations and contracts that include FAR 52.246-17, Warranty of Supplies of a Noncomplex Nature. Additional Contract Warranty Provisions for Supplies of a Noncomplex Nature (June 2009) (a) Definitions. Correction, as used in this clause, means the elimination of a defect. (b) Contractor’s obligations. When return, correction, or replacement is required, the Contractor shall be responsible for all costs attendant to the return, correction, or replacement of the nonconforming supplies. Any removal in connection with the above shall be done by the Contractor at its expense. (c) Remedies available to the Government. When the nature of the defect in the nonconforming item is such that the defect affects an entire batch or lot of material, then the equitable price adjustment shall apply to the entire batch or lot of material from which the nonconforming item was taken. (End of clause) #### 552.246-78 Inspection at Destination. As prescribed in 546.302-72 insert the following clause: Inspection at Destination (June 2009) Inspection of all purchases under this contract will be made at destination by an authorized Government representative. (End of clause) (a) If any such change causes an increase or decrease in the cost of this contract, the Contracting Officer shall make an equitable adjustment in the contract price, the delivery schedule, or both. The Contractor must assert its right to an adjustment under this clause within 30 days from the date of receipt of a delivery order. (b) The Government shall make no adjustment when supplies are identically priced for delivery regionally or nationally and the place of delivery is changed within the area to which the identical price applies. In all other cases, adjustments for changes in transportation costs under this clause shall be determined as follows: (1) If the contractor ships by contract or common carrier, price adjustments shall be determined by comparing the cost of shipments to the new destination(s), as evidenced by copy of paid freight bills supplied by the Contractor with the invoice, to one of the following: (i) The cost of shipments to the standard contract destination, as evidenced by copy of appropriate paid freight bills supplied by the Contractor. (ii) If no shipments have been made to the standard contract destination, the cost as evidenced by the applicable rates of a common or contract carrier. If carrier rates are not publicly filed with a regulatory body (e.g., interstate shipments moving by rail piggyback service), the Contractor shall provide a copy of the contract, letter agreement, or other written communication from the carrier(s) quoting the rates/charges that would have applied for shipments to the standard contract destination. (2) If (i) shipments to the new destination are made by the Contractor’s owned or leased trucks or (ii) shipments to the original destination were or would have been made by the Contractor’s owned or leased trucks, the Government shall determine the adjustment by substituting a rate equal to 70 percent of the lowest applicable rate published in common carrier rates as of the date of shipment for the Contractor’s actual rate or contemplated transportation costs. (c) If the copies of paid freight bills for a diverted shipment do not show, or make readily available, each of the following items, the Contractor shall supply a written statement showing the item(s): (1) Full name of each carrier in the routing. (2) Number of containers. (3) Gross shipping weight. (4) Actual date of shipping. (5) Freight description for the supplies as indicated in the “National Motor Freight Classification” or the “Uniform Freight Classification” (Rail). (End of clause) #### 552.252-5 Authorized Deviations in Provisions. As prescribed in 552.107-70(a), insert the following provision: Authorized Deviations in Provisions (Deviation FAR 52.252-5) (Sep 1999) (a) Deviations to FAR provisions. (1) This solicitation indicates any authorized deviation to a Federal Acquisition Regulation (48 CFR Chapter 1) provision by the addition of “(DEVIATION)” after the date of the provision, if the provision is not published in the General Services Administration Acquisition Regulation (48 CFR Chapter 5). (2) This solicitation indicates any authorized deviation to a Federal Acquisition Regulation (FAR) provision that is published in the General Services Administration Acquisition Regulation by the addition of “(DEVIATION (FAR provision no.))” after the date of the provision. (b) Deviations to GSAR provisions. This solicitation indicates any authorized deviation to a General Services Administration Acquisition Regulation provision by the addition of “(DEVIATION)” after the date of the provision. (c) “Substantially the same as” provisions. Changes in wording of provisions prescribed for use on a “substantially the same as” basis are not considered deviations. (End of provision) #### 552.252-6 Authorized Deviations in Clauses. As prescribed in 552.107-70(b), insert the following clause: Authorized Deviations in Clauses (Deviation FAR 52.252-6) (Sep 1999) (a) Deviations to FAR clauses. (1) This solicitation or contract indicates any authorized deviation to a Federal Acquisition Regulation (48 CFR Chapter 1) clause by the addition of “(DEVIATION)” after the date of the clause, if the clause is not published in the General Services Administration Acquisition Regulation (48 CFR Chapter 5). (2) This solicitation indicates any authorized deviation to a Federal Acquisition Regulation (FAR) clause that is published in the General Services Administration Acquisition Regulation by the addition of “(DEVIATION (FAR clause no.))” after the date of the clause. (b) Deviations to GSAR clauses. This solicitation indicates any authorized deviation to a General Services Administration Acquisition Regulation clause by the addition of “(DEVIATION)” after the date of the clause. (c) “Substantially the same as” clauses. Changes in wording of clauses prescribed for use on a “substantially the same as” basis are not considered deviations. (End of clause) #### 552.270-1 Instructions to Offerors—Acquisition of Leasehold Interests in Real Property. As prescribed in 570.602, insert the following provision: Instructions to Offerors—Acquisition of Leasehold Interests in Real Property (Mar 1998) (a) Definitions. As used in this provision— “Discussions” are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer’s discretion, result in the offeror being allowed to revise its proposal. “In writing” or “written” means any worded or numbered expression which can be read, reproduced, and later communicated, and includes electronically transmitted and stored information. “Proposal modification” is a change made to a proposal before the solicitation’s closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award. “Proposal revision” is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations. “Time,” if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day. (b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s). (c) Submission, modification, revision, and withdrawal of proposals. (1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages Offers must be: (i) Submitted on the forms prescribed and furnished by the Government as a part of this solicitation or on copies of those forms, and (ii) Signed. The person signing an offer must initial each erasure or change appearing on any offer form. If the offeror is a partnership, the names of the partners composing the firm must be included with the offer. (2) Late proposals and revisions. (i) The Government will not consider any proposal received at the office designated in the solicitation after the exact time specified for receipt of offers unless it is received before the Government makes award and it meets at least one of the following conditions: (A) It was sent by registered or certified mail not later than the 5th calendar day before the date specified for receipt of offers (e.g., an offer submitted in response to a solicitation requiring receipt of offers by the 20th of the month must have been mailed by the 15th). (B) It was sent by mail (or telegram or facsimile, if authorized) or hand-carried (including delivery by a commercial carrier) if it is determined by the Government that the late receipt was due primarily to Government mishandling after receipt at the Government installation. (C) It was sent by U.S. Postal Service Express Mail Next Day Service-Post Office to Addressee, not later than 5:00 p.m. at the place of mailing two working days prior to the date specified for receipt of proposals. The term “working days” excludes weekends and U.S. Federal holidays. (D) It was transmitted through an electronic commerce method authorized by the solicitation and was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals. (E) There is acceptable evidence to establish that it was received at the activity designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers, and the Contracting Officer determines that accepting the late offer would not unduly delay the procurement. (F) It is the only proposal received. (ii) Any modification or revision of a proposal or response to request for information, including any final proposal revision, is subject to the same conditions as in paragraphs (c)(2)(i)(A) through (c)(2)(i)(E) of this provision. (iii) The only acceptable evidence to establish the date of mailing of a late proposal or modification or revision sent either by registered or certified mail is the U.S. or Canadian Postal Service postmark both on the envelope or wrapper and on the original receipt from the U.S. or Canadian Postal Service. Both postmarks must show a legible date or the proposal, response to a request for information, or modification or revision shall be processed as if mailed late. “Postmark” means a printed, stamped, or otherwise placed impression (exclusive of a postage meter machine impression) that is readily identifiable without further action as having been supplied and affixed by employees of the U.S. or Canadian Postal Service on the date of mailing. Therefore, offerors or respondents should request the postal clerk to place a legible hand cancellation bull’s eye postmark on both the receipt and the envelope or wrapper. (iv) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel. (v) The only acceptable evidence to establish the date of mailing of a late offer, modification or revision, or withdrawal sent by Express Mail Next Day Service-Post Office to Addressee is the date entered by the post office receiving clerk on the “Express Mail Next Day Service-Post Office to Addressee” label and the postmark on both the envelope or wrapper and on the original receipt from the U.S. Postal Service. “Postmark” has the same meaning as defined in paragraph (c)(2)(iii) of this provision, excluding postmarks of the Canadian Postal Service. Therefore, offerors or respondents should request the postal clerk to place a legible hand cancellation bull’s eye postmark on both the receipt and the envelope or wrapper. (vi) Notwithstanding paragraph (c)(2)(i) of this provision, a late modification or revision of an otherwise successful proposal that makes its terms more favorable to the Government will be considered at any time it is received and may be accepted. (vii) An offeror may withdraw its proposal by written notice or telegram (including mailgram) received at any time before award. If the solicitation authorizes facsimile proposals, an offeror may withdraw its proposal via facsimile received at any time before award, subject to the conditions specified in the provision entitled “Facsimile Proposals.” Proposals may be withdrawn in person by an offeror or an authorized representative, if the representative’s identity is made known and the representative signs a receipt for the proposal before award. (viii) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office. (3) Any information given to a prospective offeror concerning this solicitation will be furnished promptly to all other prospective offerors, if that information is necessary in submitting offers or if the lack of it would be prejudicial to any other prospective offeror. (4) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award. (5) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer. (6) The Government will construe an offer to be in full and complete compliance with this solicitation unless the offer describes any deviation in the offer. (7) Offerors may submit proposals that depart from stated requirements. Such a proposal shall clearly identify why the acceptance of the proposal would be advantageous to the Government. The proposal must clearly identify and explicitly define any deviations from the terms and conditions of the solicitation, as well as the comparative advantage to the Government. The Government reserves the right to amend the solicitation to allow all offerors an opportunity to submit revised proposals based on the revised requirements. (d) Restriction on disclosure and use of data. An offeror that includes in its proposal data that it does not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, must meet both of the following conditions: (1) Mark the title page with the following legend: This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed—in whole or in part—for any purpose other than to evaluate this proposal. If, however, a lease is awarded to this offeror as a result of—or in connection with—the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government’s right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]. (2) Mark each sheet of data it wishes to restrict with the following legend: Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal. (e) Lease award. (1) The Government intends to award a lease resulting from this solicitation to the responsible offeror whose proposal represents the best value after evaluation in accordance with the factors and subfactors in the solicitation. (2) The Government may reject any or all proposals if such action is in the Government’s interest. (3) The Government may waive informalities and minor irregularities in proposals received. (4) The Government intends to evaluate proposals and award a lease after conducting discussions with offerors whose proposals have been determined to be within the competitive range. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals. Therefore, the offeror’s initial proposal should contain the offeror’s best terms from a price and technical standpoint. (5) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government. (6) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more contract line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government. (7) The unconditional written acceptance of an offer establishes a valid contract. (8) The Government may disclose the following information in postaward debriefings to other offerors: (i) The overall evaluated cost or price and technical rating of the successful offeror; (ii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection; and (iii) A summary of the rationale for award. (End of provision) Alternate I (Mar 1998). As prescribed in 570.602, substitute the following paragraph for paragraph (c)(2)(i) of the basic provision: (i) Any offer received at the office designated in the solicitation after the exact time specified for receipt of final proposal revisions will not be considered unless it is received before award is made and it meets one of the following conditions— Alternate II (Mar 1998). As prescribed in 570.602, substitute the following paragraph for paragraph (e)(4) of the basic provision: (4) The Government intends to evaluate proposals and award a lease without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror’s initial proposal should contain the offeror’s best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals. #### 552.270-2 Historic Preference. As prescribed in 570.602 , insert the following provision: Historic Preference (Sept 2004) (a) The Government will give preference to offers of space in historic properties following this hierarchy of consideration: (1) Historic properties within historic districts. (2) Non-historic developed and non-historic undeveloped sites within historic districts. (3) Historic properties outside of historic districts. (b) Definitions. (1) “Determination of eligibility” means a decision by the Department of the Interior that a district, site, building, structure or object meets the National Register criteria for evaluation although the property is not formally listed in the National Register (36 CFR 60.3(c)). (2) “Historic district” means a geographically definable area, urban or rural, possessing a significant concentration, linkage, or continuity of sites, buildings, structures, or objects united by past events or aesthetically by plan or physical development. A district may also comprise individual elements separated geographically but linked by association or history (36 CFR 60.3(d)). The historic district must be included in or be determined eligible for inclusion in the National Register of Historic Places. (3) “Historic property” means any pre-historic or historic district, site, building, structure, or object included in or been determined eligible for inclusion in the National Register of Historic Places maintained by the Secretary of the Interior (36 CFR 800.16(l)). (4) “National Register of Historic Places” means the National Register of districts, sites, buildings, structures and objects significant in American history, architecture, archeology, engineering and culture that the Secretary of the Interior is authorized to expand and maintain under the National Historic Preservation Act (36 CFR 60.1). (c) The offer of space must meet the terms and conditions of this solicitation. The Contracting Officer has discretion to accept alternatives to certain architectural characteristics and safety features defined elsewhere in this solicitation to maintain the historical integrity of an historic building, such as high ceilings and wooden floors, or to maintain the integrity of an historic district, such as setbacks, floor-to-ceiling heights, and location and appearance of parking. (d) When award will be based on the lowest price technically acceptable source selection process, the Government will give a price evaluation preference, based on the total annual square foot (ANSI/BOMA Office Area) cost to the Government, to historic properties as follows: (1) First to suitable historic properties within historic districts, a 10 percent price preference. (2) If no suitable historic property within an historic district is offered, or the 10 percent preference does not result in such property being the lowest price technically acceptable offer, the Government will give a 2.5 percent price preference to suitable non-historic developed or undeveloped sites within historic districts. (3) If no suitable non-historic developed or undeveloped site within an historic district is offered, or the 2.5 percent preference does not result in such property being the lowest price technically acceptable offer, the Government will give a 10 percent price preference to suitable historic properties outside of historic districts. (4) Finally, if no suitable historic property outside of historic districts is offered, no historic price preference will be given to any property offered. (e) When award will be based on the best value tradeoff source selection process, which permits tradeoffs among price and non-price factors, the Government will give a price evaluation preference, based on the total annual square foot (ANSI/BOMA Office Area) cost to the Government, to historic properties as follows: (1) First to suitable historic properties within historic districts, a 10 percent price preference. (2) If no suitable historic property within a historic district is offered or remains in the competition, the Government will give a 2.5 percent price preference to suitable non-historic developed or undeveloped sites within historic districts. (3) If no suitable non-historic developed or undeveloped site within an historic district is offered or remains in the competition, the Government will give a 10 percent price preference to suitable historic properties outside of historic districts. (4) Finally, if no suitable historic property outside of historic districts is offered, no historic price preference will be given to any property offered. (f) The Government will compute price evaluation preferences by reducing the price(s) of the offerors qualifying for a price evaluation preference by the applicable percentage provided in this provision. The price evaluation preference will be used for price evaluation purposes only. The Government will award a contract in the amount of the actual price(s) proposed by the successful offeror and accepted by the Government. (g) To qualify for a price evaluation preference, offerors must provide satisfactory documentation in their offer that their property qualifies as one of the following: (1) An historic property within an historic district. (2) A non-historic developed or undeveloped site within an historic district. (3) An historic property outside of an historic district.. (End of provision) #### 552.270-3 Parties to Execute Lease. As prescribed in 570.602, insert the following provision: Parties to Execute Lease (Sep 1999) (a) If the lease is executed by an attorney, agent, or trustee on behalf of the Lessor, an authenticated copy of his power of attorney, or other evidence to act on behalf of the Lessor, shall accompany the lease. (b) If the Lessor is a partnership, the lease shall be signed with the partnership name, followed by the name of the legally authorized partner signing the same, and, if requested by the Government, a copy of either the partnership agreement or current Certificate of Limited Partnership shall accompany the lease. (c) If the Lessor is a corporation, the lease shall be signed with the corporate name, followed by the signature and title of the officer or other person signing the lease on its behalf, duly attested, and, if requested by the Government, evidence of this authority to so act shall be furnished. (End of provision) #### 552.270-4 Definitions. As prescribed in 570.603, insert the following clause: Definitions (Sep 1999) The following terms and phrases (except as otherwise expressly provided or unless the context otherwise requires) for all purposes of this lease shall have the respective meanings hereinafter specified: (a) “Commencement Date” means the first day of the term. (b) “Contract” and “Contractor” means “Lease” and “Lessor,” respectively. (c) “Contracting Officer” means a person with the authority to enter into, administer, and/or terminate contracts and make related determinations and findings. The term includes certain authorized representatives of the Contracting Officer acting within the limits of their authority as delegated by the Contracting Officer. (d) “Delivery Date” means the date specified in or determined pursuant to the provisions of this lease for delivery of the premises to the Government, improved in accordance with the provisions of this lease and substantially complete, as such date may be modified in accordance with the provisions of this lease. (e) “Delivery Time” means the number of days provided by this lease for delivery of the premises to the Government, as such number may be modified in accordance with the provisions of this lease. (f) “Excusable Delays” mean delays arising without the fault or negligence of Lessor and Lessor’s subcontractors and suppliers at any tier, and shall include, without limitation: (1) acts of God or of the public enemy, (2) acts of the United States of America in either its sovereign or contractual capacity, (3) acts of another contractor in the performance of a contract with the Government, (4) fires, (5) floods, (6) epidemics, (7) quarantine restrictions, (8) strikes, (9) freight embargoes, (10) unusually severe weather, or (11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier. (g) “Lessor” means the sub-lessor if this lease is a sublease. (h) “Lessor shall provide” means the Lessor shall furnish and install at Lessor’s expense. (i) “Notice” means written notice sent by certified or registered mail, Express Mail or Comparable service, or delivered by hand. Notice shall be effective on the date delivery is accepted or refused. (j) “Premises” means the space described in this lease. (k) “Substantially complete” and “substantial completion” means that the work, the common and other areas of the building, and all other things necessary for the Government’s access to the premises and occupancy, possession, use and enjoyment thereof, as provided in this lease, have been completed or obtained, excepting only such minor matters as do not interfere with or materially diminish such access, occupancy, possession, use or enjoyment. (l) “Usable square feet” means the ANSI/BOMA Z65.1-1996 definition for BOMA usable office area, which means “The area where a tenant normally houses personnel and/or furniture, for which a measurement is to be computed.” (m) “Work” means all alterations, improvements, modifications, and other things required for the preparation or continued occupancy of the premises by the Government as specified in this lease. (End of clause) #### 552.270-5 Subletting and Assignment. As prescribed in 570.603, insert the following clause: Subletting and Assignment (Sep 1999) The Government may sublet any part of the premises but shall not be relieved from any obligations under this lease by reason of any such subletting. The Government may at any time assign this lease, and be relieved from all obligations to Lessor under this lease excepting only unpaid rent and other liabilities, if any, that have accrued to the date of said assignment. Any assignment shall be subject to prior written consent of Lessor, which shall not be unreasonably withheld. (End of clause) #### 552.270-6 Maintenance of Building and Premises—Right of Entry. As prescribed in 570.603, insert the following clause: Maintenance of Building and Premises—Right of Entry (Sep 1999) Except in case of damage arising out of the willful act or negligence of a Government employee, Lessor shall maintain the premises, including the building and all equipment, fixtures, and appurtenances furnished by the lessor under this lease, in good repair and condition so that they are suitable in appearance and capable of supplying such heat, air conditioning, light, ventilation, access and other things to the premises, without reasonably preventable or recurring disruption, as is required for the Government’s access to, occupancy, possession, use and enjoyment of the premises as provided in this lease. For the purpose of so maintaining the premises, the Lessor may at reasonable times enter the premises with the approval of the authorized Government representative in charge. (End of clause) #### 552.270-7 Fire and Casualty Damage. As prescribed in 570.603, insert the following clause: Fire and Casualty Damage (Sep 1999) If the entire premises are destroyed by fire or other casualty, this lease will immediately terminate. In case of partial destruction or damage, so as to render the premises untenantable, as determined by the Government, the Government may terminate the lease by giving written notice to the Lessor within 15 calendar days of the fire or other casualty; if so terminated, no rent will accrue to the Lessor after such partial destruction or damage; and if not so terminated, the rent will be reduced proportionately by supplemental agreement hereto effective from the date of such partial destruction or damage. Nothing in this lease shall be construed as relieving Lessor from liability for damage to or destruction of property of the United States of America caused by the willful or negligent act or omission of Lessor. (End of clause) #### 552.270-8 Compliance with Applicable Law. As prescribed in 570.603, insert the following clause: Compliance with Applicable Law (Sep 1999) Lessor shall comply with all Federal, state and local laws applicable to the Lessor as owner or lessor, or both, of the building or premises, including, without limitation, laws applicable to the construction, ownership, alteration or operation of both or either thereof, and will obtain all necessary permits, licenses and similar items at Lessor’s expense. The Government will comply with all Federal, state and local laws applicable to and enforceable against it as a tenant under this lease; provided that nothing in this lease shall be construed as a waiver of any sovereign immunity of the Government. This lease shall be governed by Federal law. (End of clause) #### 552.270-9 Inspection—Right of Entry. As prescribed in 570.603, insert the following clause: Inspection—Right of Entry (Sep 1999) (a) At any time and from time to time after receipt of an offer (until the same has been duly withdrawn or rejected), after acceptance thereof and during the term, the agents, employees and contractors of the Government may, upon reasonable prior notice to Offeror or Lessor, enter upon the offered premises or the premises, and all other areas of the building access to which is necessary to accomplish the purposes of entry, to determine the potential or actual compliance by the Offeror or Lessor with the requirements of the solicitation or this lease, which purposes shall include, but not be limited to: (1) Inspecting, sampling and analyzing suspected asbestos-containing materials and air monitoring for asbestos fibers; (2) Inspecting the heating, ventilation and air conditioning system, maintenance records, and mechanical rooms for the offered premises or the premises; (3) Inspecting for any leaks, spills, or other potentially hazardous conditions which may involve tenant exposure to hazardous or toxic substances; and (4) Inspecting for any current or past hazardous waste operations, to ensure that appropriate mitigative actions were taken to alleviate any environmentally unsound activities in accordance with Federal, State and local law. (b) Nothing in this clause shall be construed to create a Government duty to inspect for toxic materials or to impose a higher standard of care on the Government than on other lessees. The purpose of this clause is to promote the ease with which the Government may inspect the building. Nothing in this clause shall act to relieve the Lessor of any duty to inspect or liability which might arise as a result of Lessor’s failure to inspect for or correct a hazardous condition. (End of clause) #### 552.270-10 Failure in Performance. As prescribed in 570.603, insert the following clause: Failure in Performance (Sep 1999) The covenant to pay rent and the covenant to provide any service, utility, maintenance, or repair required under this lease are interdependent. In the event of any failure by the Lessor to provide any service, utility, maintenance, repair or replacement required under this lease the Government may, by contract or otherwise, perform the requirement and deduct from any payment or payments under this lease, then or thereafter due, the resulting cost to the Government, including all administrative costs. If the Government elects to perform any such requirement, the Government and each of its contractors shall be entitled to access to any and all areas of the building, access to which is necessary to perform any such requirement, and the Lessor shall afford and facilitate such access. Alternatively, the Government may deduct from any payment under this lease, then or thereafter due, an amount which reflects the reduced value of the contract requirement not performed. No deduction from rent pursuant to this clause shall constitute a default by the Government under this lease. These remedies are not exclusive and are in addition to any other remedies which may be available under this lease or at law. (End of clause) #### 552.270-11 Successors Bound. As prescribed in 570.603, insert the following clause: Successors Bound (Sep 1999) This lease shall bind, and inure to the benefit of, the parties and their respective heirs, executors, administrators, successors and assigns. (End of clause) #### 552.270-12 Alterations. As prescribed in 570.603, insert the following clause: Alterations (Sep 1999) The Government shall have the right during the existence of this lease to make alterations, attach fixtures, and erect structures or signs in or upon the premises hereby leased, which fixtures, additions or structures so placed in, on, upon, or attached to the said premises shall be and remain the property of the Government and may be removed or otherwise disposed of by the Government. If the lease contemplates that the Government is the sole occupant of the building, for purposes of this clause, the leased premises include the land on which the building is sited and the building itself. Otherwise, the Government shall have the right to tie into or make any physical connection with any structure located on the property as is reasonably necessary for appropriate utilization of the leased space. (End of clause) #### 552.270-13 Proposals for Adjustment. As prescribed in 570.603, insert the following clause: Proposals for Adjustment (Sep 1999) (a) The Contracting Officer may, from time to time during the term of this lease, require changes to be made in the work or services to be performed and in the terms or conditions of this lease. Such changes will be required under the Changes clause. (b) If the Contracting Officer makes a change within the general scope of the lease, the Lessor shall submit, in a timely manner, an itemized cost proposal for the work to be accomplished or services to be performed when the cost exceeds $100,000. The proposal, including all subcontractor work, will contain at least the following detail— (1) Material quantities and unit costs; (2) Labor costs (identified with specific item or material to be placed or operation to be performed); (3) Equipment costs; (4) Worker’s compensation and public liability insurance; (5) Overhead; (6) Profit; and (7) Employment taxes under FICA and FUTA. (c) The following Federal Acquisition Regulation (FAR) provisions also apply to all proposals exceeding $500,000 in cost— (1) The Lessor shall provide cost or pricing data including subcontractor cost or pricing data (48 CFR 15.403-4); and (2) The Lessor’s representative, all Contractors, and subcontractors whose portion of the work exceeds $500,000 must sign and return the “Certificate of Current Cost or Pricing Data” (48 CFR 15.406-2). (d) Lessors shall also refer to 48 CFR Part 31, Contract Cost Principles, for information on which costs are allowable, reasonable, and allocable in Government work. (End of clause) #### 552.270-14 Changes. As prescribed in 570.603, insert the following clause: Changes (Sep 1999) (a) The Contracting Officer may at any time, by written order, make changes within the general scope of this lease in any one or more of the following: (1) Specifications (including drawings and designs). (2) Work or services. (3) Facilities or space layout. (4) Amount of space, provided the Lessor consents to the change. (b) If any such change causes an increase or decrease in Lessor’s cost of or the time required for performance under this lease, whether or not changed by the order, the Contract ing Officer shall modify this lease to provide for one or more of the following: (1) A modification of the delivery date. (2) An equitable adjustment in the rental rate. (3) A lump sum equitable adjustment. (4) An equitable adjustment of the annual operating costs per usable square foot specified in this lease. (c) The Lessor must assert its right to an adjustment under this clause within 30 days from the date of receipt of the change order and must submit a proposal for adjustment. Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause excuses the lessor from proceeding with the change as directed. (d) Absent such written change order, the Government is not liable to Lessor under this clause. (End of clause) #### 552.270-15 Liquidated Damages. As prescribed in 570.603, insert the following clause: Liquidated Damages (Sep 1999) In case of failure on the part of the Lessor to complete the work within the time fixed in the lease contract or letter of award, the Lessor shall pay the Government as fixed and agreed liquidated damages, pursuant to this clause, the sum of $ for each and every calendar day that the delivery is delayed beyond the date specified for delivery of all of the space ready for occupancy by the Government. This remedy is not exclusive and is in addition to any other remedies which may be available under this lease or at law. (End of clause) #### 552.270-16 Adjustment for Vacant Premises. As prescribed in 570.603, insert the following clause: Adjustment for Vacant Premises (Sep 1999) (a) If the Government fails to occupy any portion of the leased premises or vacates the premises in whole or in part before the lease term expires, the rental rate will be reduced. (b) The rental rate will be reduced by that portion of the costs per usable square foot of operating expenses not required to maintain the space. The reduction takes effect 30 calendar days after the Government gives notice to the Lessor, and continues in effect until the Government occupies the premises or the lease expires or is terminated. (End of clause) #### 552.270-17 Delivery and Condition. As prescribed in 570.603, insert the following clause: Delivery and Condition (Sep 1999) (a) Unless the Government elects to have the space occupied in increments, the space must be delivered ready for occupancy as a complete unit. The Government reserves the right to determine when the space is substantially complete. (b) If the premises do not in every respect comply with the provisions of this lease the Contracting Officer may, in accordance with the Failure in Performance clause of this lease, elect to reduce the rent payments. (End of clause) #### 552.270-18 Default in Delivery—Time Extensions. As prescribed in 570.603, insert the following clause: Default in Delivery—Time Extensions (Sep 1999) (a) With respect to Lessor’s obligation to deliver the premises substantially complete by the delivery date, time is of the essence. If the Lessor fails to work diligently to ensure its substantial completion by the delivery date or fails to substantially complete the work by such date, the Government may by notice to the Lessor terminate this lease. Such termination is effective when received by Lessor. The Lessor and the Lessor’s sureties, if any, are jointly and severally liable for any damages to the Government resulting from such termination, as provided in this clause. The Government is entitled to the following damages: (1) The Government’s aggregate rent, estimated real estate tax, and operating cost adjustments for the firm term and all option terms of its replacement lease or leases, in excess of the aggregate rent and estimated real estate tax and operating cost adjustments for the term. If the Government procures replacement premises for a term (including all option terms) in excess of this lease term, the Lessor is not liable for excess Government rent or adjustments during such excess lease term. (2) All administrative and other costs the Government incurs in procuring a replacement lease or leases. (3) Other, additional relief provided for in this lease, at law, or in equity. (b) Damages to which the Government is entitled to under this clause are due and payable thirty (30) days following the date Lessor receives notice from the Contracting Officer specifying such damages. (c) Delivery by Lessor of less than the minimum usable square footage required by this lease shall in no event be construed as substantial completion, except as the Contracting Officer permits. (d) The Government shall not terminate this lease under this clause nor charge the Lessor with damages under this clause, if (1) the delay in substantially completing the work arises from excusable delays, and (2) the Lessor within 10 days from the beginning of any such delay (unless extended in writing by the Contracting Officer) provides notice to the Contracting Officer of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If the facts warrant, the Contracting Officer shall extend the delivery date, to the extent of such delay at no additional costs to the Government. A time extension is the sole remedy of the Lessor. (End of clause) #### 552.270-19 Progressive Occupancy. As prescribed in 570.603, insert the following clause: Progressive Occupancy (Sep 1999) The Government shall have the right to elect to occupy the space in partial increments prior to the substantial completion of the entire leased premises, and the Lessor agrees to schedule its work so as to deliver the space incrementally as elected by the Government. The Government shall pay rent commencing with the first business day following substantial completion of the entire leased premise unless the Government has elected to occupy the leased premises incrementally. In case of incremental occupancy, the Government shall pay rent pro rata upon the first business day following substantial completion of each incremental unit. Rental payments shall become due on the first workday of the month following the month in which an increment of space is substantially complete, except that should an increment of space be substantially completed after the fifteenth day of the month, the payment due date will be the first workday of the second month following the month in which it was substantially complete. The commencement date of the firm lease term will be a composite determined from all rent commencement dates. (End of clause) #### 552.270-20 Payment. As prescribed in 570.603, insert the following clause: Payment (Sep 1999) (a) When space is offered and accepted, usable square footage delivered will be confirmed by either: (1) The Government’s measurement of plans submitted by the successful offeror as approved by the Government, and an inspection of the space to verify that the delivered space conforms with such plans. (2) A mutual on-site measurement of the space if the Contracting Officer determines it necessary. (b) The Government will not pay for space in excess of the amount of usable square footage stated in the lease. (c) If the amount of usable square footage delivered is less than the amount agreed to in the lease, the lease will be modified to reflect the amount of usable space delivered and the annual rental will be adjusted as follows: Usable square feet (USF) not delivered multiplied by one plus the common area factor (CAF), multiplied by the rate per rentable square foot (RSF). That is: (End of clause) #### 552.270-21 Effect of Acceptance and Occupancy. As prescribed in 570.603, insert the following clause: Effect of Acceptance and Occupancy (Sep 1999) Neither the Government’s acceptance of the premises for occupancy, nor the Government’s occupancy thereof, shall be construed as a waiver of any requirement of or right of the Government under this Lease, or as otherwise prejudicing the Government with respect to any such requirement or right. (End of clause) #### 552.270-22 Default by Lessor During the Term. As prescribed in 570.603, insert the following clause: Default by Lessor During the Term (Sep 1999) (a) Each of the following shall constitute a default by Lessor under this lease: (1) Failure to maintain, repair, operate or service the premises as and when specified in this lease, or failure to perform any other requirement of this lease as and when required provided any such failure shall remain uncured for a period of thirty (30) days next following Lessor’s receipt of notice thereof from the Contracting Officer or an authorized representative. (2) Repeated and unexcused failure by Lessor to comply with one or more requirements of this lease shall constitute a default notwithstanding that one or all such failures shall have been timely cured pursuant to this clause. (b) If a default occurs, the Government may, by notice to Lessor, terminate this lease for default and if so terminated, the Government shall be entitled to the damages specified in the Default in Delivery-Time Extensions clause. (End of clause) #### 552.270-23 Subordination, Nondisturbance and Attornment. As prescribed in 570.603, insert the following clause: Subordination, Nondisturbance and Attornment (Sep 1999) (a) Lessor warrants that it holds such title to or other interest in the premises and other property as is necessary to the Government’s access to the premises and full use and enjoyment thereof in accordance with the provisions of this lease. Government agrees, in consideration of the warranties and conditions set forth in this clause, that this lease is subject and subordinate to any and all recorded mortgages, deeds of trust and other liens now or hereafter existing or imposed upon the premises, and to any renewal, modification or extension thereof. It is the intention of the parties that this provision shall be self-operative and that no further instrument shall be required to effect the present or subsequent subordination of this lease. Government agrees, however, within twenty (20) business days next following the Contracting Officer’s receipt of a written demand, to execute such instruments as Lessor may reasonably request to evidence further the subordination of this lease to any existing or future mortgage, deed of trust or other security interest pertaining to the premises, and to any water, sewer or access easement necessary or desirable to serve the premises or adjoining property owned in whole or in part by Lessor if such easement does not interfere with the full enjoyment of any right granted the Government under this lease. (b) No such subordination, to either existing or future mortgages, deeds of trust or other lien or security instrument shall operate to affect adversely any right of the Government under this lease so long as the Government is not in default under this lease. Lessor will include in any future mortgage, deed of trust or other security instrument to which this lease becomes subordinate, or in a separate nondisturbance agreement, a provision to the foregoing effect. Lessor warrants that the holders of all notes or other obligations secured by existing mortgages, deeds of trust or other security instruments have consented to the provisions of this clause, and agrees to provide true copies of all such consents to the Contracting Officer promptly upon demand. (c) In the event of any sale of the premises or any portion thereof by foreclosure of the lien of any such mortgage, deed of trust or other security instrument, or the giving of a deed in lieu of foreclosure, the Government will be deemed to have attorned to any purchaser, purchasers, transferee or transferees of the premises or any portion thereof and its or their successors and assigns, and any such purchasers and transferees will be deemed to have assumed all obligations of the Lessor under this lease, so as to establish direct privity of estate and contract between Government and such purchasers or transferees, with the same force, effect and relative priority in time and right as if the lease had initially been entered into between such purchasers or transferees and the Government; provided, further, that the Contracting Officer and such purchasers or transferees shall, with reasonable promptness following any such sale or deed delivery in lieu of foreclosure, execute all such revisions to this lease, or other writings, as shall be necessary to document the foregoing relationship. (d) None of the foregoing provisions may be deemed or construed to imply a waiver of the Government’s rights as a sovereign. (End of clause) #### 552.270-24 Statement of Lease. As prescribed in 570.603, insert the following clause: Statement of Lease (Sep 1999) (a) The Contracting Officer will, within thirty (30) days next following the Contracting Officer’s receipt of a joint written request from Lessor and a prospective lender or purchaser of the building, execute and deliver to Lessor a letter stating that the same is issued subject to the conditions stated in this clause and, if such is the case, that (1) the lease is in full force and effect; (2) the date to which the rent and other charges have been paid in advance, if any; and (3) whether any notice of default has been issued. (b) Letters issued pursuant to this clause are subject to the following conditions: (1) That they are based solely upon a reasonably diligent review of the Contracting Officer’s lease file as of the date of issuance; (2) That the Government shall not be held liable because of any defect in or condition of the premises or building; (3) That the Contracting Officer does not warrant or represent that the premises or building comply with applicable Federal, State and local law; and (4) That the Lessor, and each prospective lender and purchaser are deemed to have constructive notice of such facts as would be ascertainable by reasonable prepurchase and precommitment inspection of the Premises and Building and by inquiry to appropriate Federal, State and local Government officials. (End of clause) #### 552.270-25 Substitution of Tenant Agency. As prescribed in 570.603, insert the following clause: Substitution of Tenant Agency (Sep 1999) The Government may, at any time and from time to time, substitute any Government agency or agencies for the Government agency or agencies, if any, named in the lease. (End of clause) #### 552.270-26 No Waiver. As prescribed in 570.603, insert the following clause: No Waiver (Sep 1999) No failure by either party to insist upon the strict performance of any provision of this lease or to exercise any right or remedy consequent upon a breach thereof, and no acceptance of full or partial rent or other performance by either party during the continuance of any such breach shall constitute a waiver of any such breach of such provision. (End of clause) #### 552.270-27 Integrated Agreement. As prescribed in 570.603, insert the following clause: Integrated Agreement (Sep 1999) This Lease, upon execution, contains the entire agreement of the parties and no prior written or oral agreement, express or implied, shall be admissible to contradict the provisions of the Lease. (End of clause) #### 552.270-28 Mutuality of Obligation. As prescribed in 570.603, insert the following clause: Mutuality of Obligation (Sep 1999) The obligations and covenants of the Lessor, and the Government’s obligation to pay rent and other Government obligations and covenants, arising under or related to this Lease, are interdependent. The Government may, upon issuance of and delivery to Lessor of a final decision asserting a claim against Lessor, set off such claim, in whole or in part, as against any payment or payments then or thereafter due the Lessor under this lease. No setoff pursuant to this clause shall constitute a breach by the Government of this lease. (End of clause) #### 552.270-29 Acceptance of Space. As prescribed in 570.603, insert the following clause: Acceptance of Space (Sep 1999) (a) When the lessor has completed all alterations, improvements, and repairs necessary to meet the requirements of the lease, the lessor shall notify the Contracting Officer. The Contracting Officer or designated representative shall promptly inspect the space. (b) The Government will accept the space and the lease term will begin after determining that the space is substantially complete and contains the required usable square footage as indicated in Paragraph 1.1, Amount and Type of Space, of this solicitation.