Skip to main content
GSAM

GSAM

Change Number: Change 178 GSAR Case 2020-G511
Effective Date: 03/25/2024

519.705-7 Liquidated damages.

519.705-7 Liquidated damages.

(a) Initial assessment. The contracting officer shall provide the SBTA an information copy of his or her initial assessment that the contractor did not make a good faith effort to comply with the plan.

(b) Final decision. Before making a final decision, the contracting officer shall consider all pertinent available information including the contractor’s response, if any, to the contracting officer’s notification letter required by FAR 19.705-7 that the contractor did not comply with the plan. Document the contracting officer’s decision in a “final decision”, which is appealable by the contractor under the “Disputes” clause of the contract. Provide the SBTA a copy of the contracting officer’s final decision assessing liquidated damages. In addition to the FAR provisions, include in the final decision letter:

(1)  A description of the contractor’s failure.

(2)  Reference to the appropriate contract terms.

(3)  A statement of the factual areas of agreement and disagreement.

(4)  A statement of the contracting officer’s decision with supporting rationale.

(5)  A demand for liquidated damages.

(6)  An explanation of the contractor’s appeal rights.

(c) Funds withheld from payments. If funds to collect liquidated damages are withheld from payments due, the funds may be returned to the applicable GSA account along with other funds that were obligated but not expended. If a commercial plan is involved, or if all payments have been made under a contract with an individual contract plan, instruct the contractor to submit a check to GSA. The GSA Office of Finance will transfer the funds to the Treasury Department for deposit in the general receipts account.

(d)  The contracting officer shall submit to the SBTA his or her final decision assessing liquidated damages.