Skip to main content
DAFFARS

DAFFARS

Change Number: DAFAC 2024-0612
Effective Date: 06/12/2024

Subpart 5333.2 – DISPUTES AND APPEALS

Subpart 5333.2 – DISPUTES AND APPEALS

5333.214 Alternate Dispute Resolution (ADR)

(a) For ACAT I and II programs, the contracting officer must establish an agreement between the Government and the contractor, such as a memorandum of understanding, that outlines the intent of the parties with respect to the use of ADR. Contracting officers must consider establishing ADR agreements for other programs and acquisitions.

(c) The acquisition team must use ADR to the maximum extent practicable (See DAFPD 51-12 , Negotiation and Dispute Resolution). ADR must also be used to resolve protests to the maximum extent practicable. The acquisition team must attempt to use ADR prior to the commencement of litigation once unassisted negotiations have reached an impasse. Further, ADR must be offered in litigation, unless one of the exceptions in 5 U.S.C. 572(b) applies or the policy set forth by Deputy General Counsel (Contractor Responsibility & Conflict Resolution ( SAF/GCR)) indicates that ADR is not appropriate.

5333.290 Claims and Terminations for Default

(a) If a contractor submits an uncertified claim exceeding $100,000, the contracting officer must notify the contractor, in writing, of its failure to certify as required by the Contract Disputes statute ( 41 U.S.C. §§ 7101-7109). The notice must state that a final decision will not be issued until the claim is certified.

(b) If the potential dispute regards any intellectual property (IP) matter, the contracting officer shall request DAF IP Cadre review by contacting the DAF IP Cadre Workflow. The term "IP matter" includes, but is not limited to, failure to deliver IP (e.g., technical data, computer software, contract administration information) that complies with the contract, nonconforming/unjustified markings affixed to IP deliverables).

(c) Prior to making a final decision on a claim or termination for default (including a termination for cause under FAR Part 12), the contracting officer must refer the proposed final decision to the cognizant legal office for legal advice, ADR suitability, and appropriate dispute resolution strategies. The contracting officer, with the assistance of the cognizant legal office, must seek review by AF/JACQ of all proposed final decisions. At the same time, the contracting officer must provide SAF/GCR with any proposed final decision on a claim involving PEO programs and any proposed final decision on a claim greater than $500,000. The contracting officer or the referring person must promptly notify SAF/GCR and their SCO with all known information relating to any recommended termination for default.

(d) The contracting officer must use ADR to the maximum extent practicable to resolve a Department of the Air Force affirmative contract claim (such as defective pricing, liquidated damages, etc.) when unassisted negotiations reach an impasse as determined by the SCO. The contracting officer must provide to AF/JACQ, with a copy to SAF/GCR, any audit or other findings indicating Department of the Air Force entitlement torecovery greater than $500,000 where unassisted negotiations have reached an impasse, in order to develop a dispute resolution strategy. Government claims must be formally asserted [issuance of a Contracting Officer’s Final Decision ( FAR33.206)]within 6 years after the accrual of the claim.

5333.291 Appeals to the Armed Services Board of Contract Appeals (ASBCA)

(a) AF/JACQ represents the Department of the Air Force in appeals to the ASBCA.

(b) If the contractor files an appeal with the ASBCA, the contracting officer must notify the SCO and forward to AF/JACQ and the cognizant legal office a copy of any notice of appeal to the ASBCA, along with the envelope in which the notice was received. If the contractor files an appeal with the contracting officer instead of the ASBCA, the contracting officer must immediately notify AF/JACQ of the date the appeal was received and forward to AF/JACQ and the cognizant legal office a copy of the appeal and a copy of the envelope in which the appeal was received. The contracting officer must forward the original appeal and envelope to AF/JACQ, which will then forward the appeal and envelope to the ASBCA, as necessary.

(c) The contracting officer must prepare a “Rule 4 file” for any appeal to the ASBCA in accordance with Rule 4 of the ASBCA rules (see DFARS Appendix A, Part 2). The contracting officer must consult with AF/JACQ before including in the Rule 4 file any legal opinions or intra-governmental or inter-governmental documents as described in DoD Directive 5400.07, DoD Freedom of Information Act Program, and FAR 24.2.

(d) While an appeal is pending, the contracting officer along with the program manager/user/functional Commander and SJA will support the assigned trial attorney as required including; identifying and locating government witnesses, gathering contractual documents and other physical evidence for conferences and hearings necessary to defend or otherwise dispose of an appeal.

(e) Once the Rule 4 file is complete, AF/JACQ will file it with the ASBCA on behalf of the contracting officer.

5333.292 Appeals to the United States Court of Federal Claims (COFC)

(a) The Department of Justice represents the Department of the Air Force in appeals brought before the COFC. The Air Force Commercial Litigation Field Support Center ( AF/JACQ) serves as the Department of the Air Force counsel with the Department of Justice in such appeals.

(b) The contracting officer must notify the cognizant legal office and the SCO of any notice of appeal to the COFC. The cognizant legal office must forward a copy of the notice to SAF/GCR and AF/JACQ.

(c) The contracting officer must assist the cognizant legal office in preparing the litigation report. The contracting officer must obtain approval from the AF/JACQ trial attorney prior to releasing the litigation report outside government.